CORCORAN CALIFORNIA CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Endorsement is Void Where Compliance is Impossible

September 21, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Sixth Circuit found that the insured’s loss of property due to fire was covered despite noncompliance with an endorsement requiring encompassing the property. 3371 Reading, LLC v. Liberty Mut Group, Inc., et al., 2026 U.S. App. LEXIS 19156 (6th Cir. June 29, 2026). The insured, 3371 Reading, owned a building undergoing renovation. After the structure burned down, 3371 Reading made a claim under its policy with Ohio Casualty Insurance Company. Ohio Casualty relied on an endorsement requiring fencing round the jobsite. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Risk Reset: Concerns Top of Mind for Top Construction Law Firms

September 28, 2026 — David McMillin - Construction Executive
In the summer of 2025, contractors were consumed by one major issue: tariffs. Owners, builders and suppliers were trying to understand how shifting trade policy would affect bid pricing and ongoing projects. While those concerns have eased after a Supreme Court ruling, some of the industry’s top legal experts—all of whom practice at some of CE’s Top 50 Construction Law Firms—point to a different set of worries that are keeping their clients up at night and keeping their offices busy. Inflation is not fading away, creating continued price challenges. Artificial intelligence is moving at a breakneck pace, offering potential time-saving benefits paired with major liability concerns. The federal government continues to make surprising policy changes, and contractors remain focused on managing financial risk across increasingly complex projects. Reprinted courtesy of David McMillin, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

GRSM Trial Team Holds Alameda County Asbestos Verdict to $900,000 Against $50 Million Demand

July 27, 2026 — Gordon Rees Scully Mansukhani
Gordon Rees Scully Mansukhani Partners John Katerndahl and Vincent Gunter recently obtained an outstanding trial result for a manufacturer of asbestos-containing electrical cable, holding a jury verdict to $900,000 against a $50 million demand following an eight-week trial in Alameda County Superior Court, which is among the most challenging asbestos venues in the country. The GRSM team also included Associate Brandon Sanchez, on-site trial Paralegal Laura Vitanova, and Paralegal Kerrie Lease. The plaintiffs, the surviving spouse and four children of a former painter who died of mesothelioma, alleged that the decedent was exposed to asbestos from the company’s electrical cable during construction of a California nuclear power facility. GRSM’s client was the sole remaining defendant at trial. The plaintiffs asked the jury for $50 million and called 15 witnesses across their case-in-chief and rebuttal. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

---

LA Scores Major Victory in a High-Exposure Premises Liability Action

July 06, 2026 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Our firm is proud to announce a decisive defense victory obtained by Partner Daniel Crespo and Associate Lauren Landau for our client in a high-exposure premises liability action arising from a 2022 incident at an active school construction site in Perris, California. On March 10, 2026, the Riverside County Superior Court granted Summary Judgment in full for our client, dismissing all claims brought by Plaintiff, who alleged she tripped and fell over a curb while picking up her daughter from school and sustained ankle and wrist injuries as a result. Through meticulous preparation and the strategic use of construction plans, contractual documents, and onsite surveillance video evidence, our team demonstrated that our client had no ownership, possession, or control over the portion of the existing sidewalk where the incident occurred, with construction plans unambiguously designating the area as pre-existing concrete outside our client’s scope of work, and the Construction Services Agreement expressly reserving control over all existing site improvements to the school district. Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

---

Wadsworth v. Regional Rail Partners — Verified Statements of Claim Under the Colorado Public Works Act

August 25, 2026 — Olivia Barden - Colorado Construction Litigation Blog
Editor’s Note: Wadsworth Revisited In August 2024, following the Colorado Court of Appeals’ decision in Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners, we published Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims. At the time, the decision warranted a significant warning to contractors and subcontractors performing public work in Colorado. The Court of Appeals concluded that Wadsworth’s verified statement of claim improperly included unliquidated delay damages and that, because the claim was excessive, Wadsworth forfeited its right to recover the amounts included in the claim. We cautioned contractors to carefully scrutinize verified statements of claim and to avoid including unliquidated damages or amounts that were not yet due and payable. The Colorado Supreme Court has now reversed that decision. Read the full story...
Reprinted courtesy of Olivia Barden, Higgins, Hopkins, McLain & Roswell, LLC

---

Modular Construction’s Hidden Risk: Where Things Go Wrong Between the Factory and the Field

June 15, 2026 — Jack Mayo - ConsensusDocs
Introduction As modular and prefabricated construction methods are increasingly adopted, so too are the potential challenges that come with them. The appeal is straightforward: faster timelines, controlled fabrication environments, and reduced on-site labor demands. But the risks that accompany these benefits are often less clear—and, in many cases, poorly defined. For example, what happens when a prefabricated component is delayed past its installation window? Who is responsible for a defect discovered inside a sealed, installed module? What happens to warranty obligations when a prefabricated component must be modified on site? Read the full story...
Reprinted courtesy of Jack Mayo, Jones Walker LLP
Mr. Mayo may be contacted at jmayo@joneswalker.com

---

Navigating Timelines and Technology: Patent Strategies for Space and Earth

June 01, 2026 — Kate Nuehring Su & Vanessa Wang - Engineering News-Record
More than half a century after the Apollo 11 landing fulfilled President John F. Kennedy’s bold vision, the global race back to the Moon is no longer theoretical. With renewed attention on NASA’s Artemis program and a surge of commercial investment in space infrastructure, lunar exploration is again shaping technology priorities here on Earth. Reprinted courtesy of Kate Nuehring Su, Engineering News-Record and Vanessa Wang, Engineering News-Record Read the full story...
ENR may be contacted at enr@enr.com

---