Ashton Illinois Construction Expert Witness Directory

Sausage-Making Often Relies on the Good Sense of the Chef Rather than the Recipe

June 23, 2026 — Garret D. Murai - California Construction Law Blog
Even for lawyers, the rules governing litigation can get complex and convoluted. Does something need to be filed? What needs to be filed? When is the deadline for filing? Simple questions with not always with straightforward answers. This was the case in R & J Sheet Metal, Inc. v. W.E. O’Neil Construction Co. of California, 111 Cal.App.5th 878 (2025), which involved sheet metal panels lost when they fell into the Port of Long Beach harbor. Read the full story...
Reprinted courtesy of Garret D. Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Real Estate & Construction News Roundup (8/19/26) – Single-Family Housing Investors Worry, Confidence in Multifamily REITs and Construction Backlog Falls

September 08, 2026 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, U.S. Chamber of Commerce creates Housing Advisory Council, a legal battle develops over new federal rules related to mortgage escrow accounts, hospitality dealmakers pursue ‘bigger, higher-conviction’ M&A, and more!

In the wake of the 21st Century ROAD to Housing Act becoming law, the U.S. Chamber of Commerce has created a Housing Advisory Council with the goal of advancing market-driven policies that help increase housing supply and promote affordability. (Julie Strupp, Multifamily Dive)
Investors in the single-family housing market are increasingly concerned about interest rates, rising insurance and home costs, and the ongoing war with Iran. (Diana Olick, CNBC)
A legal battle is brewing over new federal rules related to accounts that hold money to pay homeowners’ property taxes and insurance payments. (Sarah Agostino, CNBC)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Consider The Limited Warranty from Your Homebuilder

July 06, 2026 — David Adelstein - Florida Construction Legal Updates
When purchasing a home from a homebuilder, there is an important consideration when it comes to the limited warranty you receive around the time you close on the home. That limited warranty likely includes an arbitration provision requiring you to arbitrate your disputes, such as construction defect claims, against the homebuilder. That arbitration provision will most likely include all claims, including statutory claims (such as a statutory violation of a building code claim), requiring you to arbitrate, as opposed to litigate, your disputes against the homebuilder. This is an important consideration. If the arbitration provision does not allow you to arbitrate all of your claims, and eliminates your rights to legitimate statutory claims, the arbitration provision could be unenforceable. By way of example, in a residential construction defect dispute, Anderson v. Taylor Morrison of Florida, Inc., 223 So.3d 1088 (Fla. 2d DCA 2017), the appeal turned on whether the arbitration provision in the homebuilder’s limited warranty was valid. The homeowners took possession of their home in 2009. In 2015, the homeowners served a Florida Statutes Chapter 558 notice of construction defects that included a statutory violation of a building code claim under Florida Statute §553.84. The limited warranty included an arbitration provision that specified it was the “exclusive remedy” for all disputes arising out of or related to the warranty or issues with the home and property. When read together with the warranty’s disclaimer that precluded claims not covered by the warranty “whether in contract, tort, or otherwise,” the statutory building code violation claim could not be remedied through arbitration because it fell outside the warranty’s coverage. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Did You Know: Unique Legal Considerations for Animal Care Facilities

August 24, 2026 — Hannah Skidmore - Construction Executive
Animal care facilities are highly specialized environments that require expertise far beyond traditional commercial or even standard medical construction. Whether designing and building animal shelters, doggy daycares, veterinary clinics or full-service animal hospitals, these facilities operate under conditions that introduce unique challenges related to sanitation, durability, animal behavior and operational workflows. Because of these complexities, projects that fail to account for animal care requirements adequately often encounter costly issues—many of which result in litigation. Below are real-world examples drawn from expert witness work, followed by proactive best practices construction professionals should apply to future animal care projects. Reprinted courtesy of Hannah Skidmore, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

HHMR and Every One of its Partners Recognized by Legal 500 in Denver Elite – Real Estate

April 20, 2026 — David McLain - Colorado Construction Litigation Blog
Higgins, Hopkins, McLain & Roswell, LLC is pleased to announce its recognition as a Tier 1 firm in the Denver Elite rankings for Real Estate, a category that includes construction law and construction litigation, by The Legal 500. In addition, each of the firm’s partners has been individually recognized in the same rankings. The firm’s individual recognitions include:

David M. McLain — Tier 1
Ricky L. Nolen, Jr. — Tier 2
Lisa Bondy Dunn — Tier 3

Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Nordics Are Europe’s Next Data Center Hub

October 05, 2026 — Aarni Heiskanen - AEC Business
On September 9, 2026, Google announced its largest single investment in Europe. The company commits at least €13 billion to Finnish data centers and energy infrastructure in 2027 and 2028, expanding the existing Hamina campus and adding three new sites in Kajaani, Muhos, and Vaala. For the construction sector, this is great news: thousands of hectares, dozens of buildings, and a construction program that will extend well beyond the two-year investment window. Four Sites, One Regional Cluster Google is not a newcomer in Finland. Back in 2009, it converted a former paper mill in Hamina into a seawater-cooled data center. It has invested around €4.5 billion there over 15 years, and the site’s waste heat already feeds Hamina’s district heating network. The new program shifts the center of gravity north, to the border of North Ostrobothnia and Kainuu. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Trend Continues Where Unlicensed Contractors Have No Recourse

July 13, 2026 — David Adelstein - Florida Construction Legal Updates
There’s been a recent trend in Florida case law that has figuratively “killed” unlicensed contractors. Here’s another one. The moral to this trend and case is simple: make sure you have the proper licenses prior to serving as a contractor under Florida law. Trying to be cute, as seemed to be the situation in this case with a creative argument, is not an argument that will carry the day and your resources will be devoted to being creative versus the ultimate merits of the dispute. In Ramindesign, LLC v. Skarzynski, 2026 WL 1649571 (S.D.Fla. 2026) an owner of real property hired a company to design and construct a spec home on the property. The company and its owner were NOT licensed contractors. The contract stated the company was serving as a “spec developer” and referred to it as the contractor throughout the contract. Other than this, the contract was set up as a cost plus a fee. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

ASHTON ILLINOIS CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES