Auburn Illinois Construction Expert Witness Directory

When Projects Go Off Schedule: Navigating Construction Delays and Disputes

October 20, 2026 — Shay Kulkarni - Peckar & Abramson, P.C.
Shay Kulkarni, Partner in P&A’s San Diego office, was recently featured on Racho Mesa Insurance Services’ StudioOne™ Safety and Risk Management Podcast Network, in an episode titled, “When Projects Go Off Schedule: Navigating Construction Delays and Disputes.” During the episode, Shay joins Josh Hill, Surety Account Executive at Rancho Mesa, to discuss the best practices for navigating delays, disruptions, and disputes that arise during construction projects. The conversation explores how careful contract review, thorough project documentation, timely notice, and proactive risk management can help contractors safeguard their rights and more effectively address potential conflicts. Read the full story...
Reprinted courtesy of Shay Kulkarni, Peckar & Abramson, P.C.
Mr. Kulkarni may be contacted at skulkarni@pecklaw.com

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Traub Lieberman Recognized in the 2026 Edition of Chambers USA

June 29, 2026 — Traub Lieberman
In the 2026 edition of Chambers USA, Traub Lieberman has been awarded rankings in the following categories: Illinois – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "The team are technically very strong, responsive, and on top of their cases." Florida – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "Traub Lieberman Straus & Shrewsberry distinguishes itself through a combination of deep subject-matter expertise, responsiveness, and practical risk-management orientation." Commenters went on to say: “The team has deep knowledge of Florida property insurance statutes, regulations and case law, enabling effective handling of disputes, appeals and third-party litigation." Read the full story...
Reprinted courtesy of Traub Lieberman

Additional Insureds Obligated to Meet Self-Insured Retention

October 20, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court found that the additional insureds had to meet the policy’s self-insured retention before a duty to defend was triggered. Amerisure Ins. Co. v. Premier Design & Build Group, LLC, 2026 U.S. Dist. LEXXIS 170741 (N.D. Ill. July 31, 2026). Amerisure issued CGL and umbrella policies to Premier Design & Build Group, LLC. Amerisure had the right and duty to defend in certain suits for property damage under both policies. Premier contracted with MG East, LLC (MGE) to build three buildings. After the buildings were constructed, MG filed suit against Premier in state court, seeking recovery for allegedly defective installation of the roof, flashing, and gutters on each of the buildings. Premier had subcontracted with Tecta American Sough Florida, Inc. to install the flashing. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Court Finds Potential Conflicts In Denying Insurer’s Motion to Dismiss Claim for Independent Counsel

October 12, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The District Court denied the insurer’s motion to dismiss the additional insured’s claim that the appointment of independent counsel was required. S. Cal. Edison Co. v. Travelers Prop. Cas. Co of Am., 2025 U.S. DIst. LEXIS 148495 (C.D Calif. July 15, 2025). Southern California Edison Company (SCE) entered a Master Services Agreement with its contractor, SASCO whereby SASCO agreed to provide services concerning electrical pole repair and replacement. SASCO was required to obtain primary and excess general liability policies and to name SCE as an additional insured. SASCO obtained such policies from Travelers, naming SCE as an additional insured. The policies limited coverage for SCE to covered damages arising from SASCO’s work. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

HDR Agreed to $12M Settlement With Miami Bridge Design-Build Team

May 12, 2026 — Richard Korman - Engineering News-Record
HDR last year agreed to pay $12 million to the design-build construction contractor Archer Western-de Moya Group to settle its claims that the engineer had incompletely designed and under-designed Miami's new Signature Bridge when the joint venture committed to a fixed price prior to construction in 2018. Read the full story...
Reprinted courtesy of Richard Korman, Engineering News-Record
Mr. Korman may be contacted at kormanr@enr.com

The Most Expensive Signature to Not Get: Why Change Orders Matter

August 16, 2026 — Kathryne E. Baldwin - Wilke Fleury
George Bernard Shaw has a quote we use a lot in my family: “The single biggest problem in communication is the illusion that it has taken place.” This is pertinent to contractors and homeowners alike because the cost of failing to get proper signatures on documents like construction contracts, and particularly, change orders, is heavy. Both contractors and homeowners are in the same boat as far as wanting to complete a job as swiftly as possible: contractors go on to their next job and homeowners can return to peace in their home. This is prime territory for either party to suggest the work be completed today and the contract or change order executed tomorrow, or even later. However, without a contract, there is no memorialization of the communication between the parties, which can lead to confusion and missed expectations on both sides. Construction plans are rarely as neat and tidy as they originally seem to be. A contractor may uncover unforeseen conditions, an owner may request additional work or changes that require additional work, or weather interferes with project schedules or the work itself. Unfortunately, the signature that never gets collected can become one of the most expensive omissions on a project – for both sides. Read the full story...
Reprinted courtesy of Kathryne E. Baldwin, Wilke Fleury
Ms. Baldwin may be contacted at kbaldwin@wilkefleury.com

Could Your Project-Level AI Prompt Become the Other Side’s Smoking Gun?

October 20, 2026 — Ryan Glass - ConsensusDocs
A dispute is brewing on the project. Wanting a quick assessment, the project manager opens ChatGPT, Claude, or another generative artificial intelligence (“AI”) platform. The project manager types the dispute background into the prompt, including concerns, explanations, and a frank discussion of what may have gone wrong on the contractor-side. The AI response identifies potential weaknesses in the contractor’s position, including possible failures to meet contractual obligations. Unhappy with the answer, the project manager starts a new chat, revises the prompt, and tries again. If the dispute escalates to arbitration or litigation, can the owner force the contractor to provide these prompts and the resulting responses? Frustratingly, the answer is: it depends. Courts have reached different conclusions. For now, the safest course is to involve your counsel before using AI to evaluate a demand letter, default notice, or threatened lawsuit, or before using AI to draft dispute-related emails, claim letters, or other communications that contain project-specific facts. Otherwise, what feels like a private conversation may later become key evidence for the opposing party. Read the full story...
Reprinted courtesy of Ryan Glass, Jones Walker LLC
Mr. Glass may be contacted at rglass@joneswalker.com

AUBURN ILLINOIS CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES