MURDOCK KANSAS CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Lewis Brisbois Welcomes Clients and Community Leaders to New Garden City Office Opening

July 27, 2026 — Lewis Brisbois
On July 15, Lewis Brisbois hosted a ribbon-cutting event for its new Garden City office, which opened in April to serve the Long Island community and beyond. The event was attended by more than 100 people, including Lewis Brisbois attorneys and staff as well as clients, local business and government leaders, Nassau County Supreme Court judges, and members of the press. Nassau County Executive Bruce Blakeman delivered remarks and cut the ribbon for the office. Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Landlord Determined to Not Qualify as Additional Insured

September 08, 2026 — Tred R. Eyerly - Insurance Law Hawaii
In a dispute between two insurers, the Second Circuit affirmed the district court’s determination that the landlord was not an additional insured under the tenant’s policy. Peleus Ins. Co. v. Am. European Ins. Co., 2026 U.S. App. LEXIS 17981 June 22, 2026). Blossom Miller sued 57th Avenue and 21st Century in state court alleging that she was injured when she tripped on the sidewalk in front of the leased premises (the “Miller Action”). The premises was leased by 57th Avenue to 21st Century. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Traub Lieberman Recognized in the 2026 Edition of Chambers USA

June 29, 2026 — Traub Lieberman
In the 2026 edition of Chambers USA, Traub Lieberman has been awarded rankings in the following categories: Illinois – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "The team are technically very strong, responsive, and on top of their cases." Florida – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "Traub Lieberman Straus & Shrewsberry distinguishes itself through a combination of deep subject-matter expertise, responsiveness, and practical risk-management orientation." Commenters went on to say: “The team has deep knowledge of Florida property insurance statutes, regulations and case law, enabling effective handling of disputes, appeals and third-party litigation." Read the full story...
Reprinted courtesy of Traub Lieberman

---

Self-Healing Infrastructure Could Pave the Road to the Future

May 05, 2026 — Allan C. Van Vliet - Gravel2Gavel Construction & Real Estate Law Blog
A single hairline crack in a bridge deck can seem insignificant. But left undetected, minor cracks and fissures expand, water seeps in, steel corrodes and repair costs start to increase. This risk multiplies across thousands of miles of aging highways and bridges nationwide. As infrastructure endures increasing strain from heavier traffic, extreme weather and deferred maintenance, engineers are exploring “self-healing” systems, where streets and bridges are built with materials that can repair themselves. Concrete, asphalt and composites capable of detecting and mending microcracks autonomously are moving from laboratory research to pilot projects. But while emerging technology promises longer-lasting infrastructure, it also raises questions about long-term maintenance, performance guarantees, procurement frameworks and risk allocation. Read the full story...
Reprinted courtesy of Allan C. Van Vliet, Pillsbury
Mr. Van Vliet may be contacted at allan.vanvliet@pillsburylaw.com

---

Inaccurate Representations Can Lead to Differing Site Conditions Claim

May 26, 2026 — David Adelstein - Florida Construction Legal Updates
In the prior posting, I discussed a case dealing with a differing site condition. In that case, the owner did not have an affirmative duty to make a representation and there was no inaccurate representation made by the owner that misled the contractor. Well, what about when there is an inaccurate misrepresentation regarding the site? This was the circumstance in an older Florida case where a dredging contractor had a successful differing site conditions claim. See Jacksonville Port Authority v. Parkhill-Goodloe, Co., Inc., 362 So.2d 1009 (Fla. 1st DCA 1978). The government provided inaccurate information as to the lack of rock that would be encountered during the dredging that was relied on by the dredging contractor. But the government had “superior knowledge” that there was rock in an adjacent location based on a prior claim from a contractor, yet the government did not disclose the possibility that rock could be encountered. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

From CERCLA to Drinking Water: D.C. Circuit’s PFAS Ruling Enters a Second Regulatory Fight

October 06, 2026 — Ashleigh K. Myers, Amanda G. Halter & Jillian Marullo - Gravel2Gavel Construction & Real Estate Law Blog
On August 18, 2026, a unanimous panel of the U.S. Court of Appeals for the D.C. Circuit upheld EPA’s designation of perfluorooctanoic acid (PFOA) and perfluorooctanesulfonic acid (PFOS) as hazardous substances under the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA or Superfund). In Chamber of Commerce of the United States v. EPA, the court rejected challenges to EPA’s interpretation of CERCLA Section 102(a), the adequacy of its notice and comment process, its analysis of costs and benefits, and its decision to proceed despite uncertainty about future response actions and costs. This decision is already being invoked in a separate D.C. Circuit challenge to EPA’s 2024 PFAS drinking water rule promulgated under the Safe Drinking Water Act (SDWA). Six days after the CERCLA decision, respondent intervenors cited it as supplemental authority in American Water Works Association v. EPA, No. 24-1188, ahead of oral argument scheduled for September 18, 2026. The Chamber of Commerce decision may assist the respondent intervenors on certain notice and comment and economic analysis arguments, but its significance should not be overstated. The principal challenges to the standards for the four PFAS subject to EPA’s Hazard Index-based maximum contaminant level (MCL) turn on requirements specific to the SDWA, and EPA itself now agrees that those provisions were promulgated through an unlawful process. Reprinted courtesy of Ashleigh K. Myers, Pillsbury, Amanda G. Halter, Pillsbury and Jillian Marullo, Pillsbury Ms. Myers may be contacted at ashleigh.myers@pillsburylaw.com Ms. Halter may be contacted at amanda.halter@pillsburylaw.com Ms. Marullo may be contacted at jillian.marullo@pillsburylaw.com Read the full story...

---

California Poised for the Most Significant Residential Construction Defect Reforms in Decades

September 01, 2026 — Thomas D. Fama & Andrew J. Mallon - Wood Smith Henning Berman
The California Legislature is considering legislation that would dramatically alter the landscape of residential construction defect litigation. Assembly Bill 1903, currently pending before the Senate Judiciary Committee, proposes extensive amendments to California's Right to Repair Act (Civil Code sections 895-945.5) that would substantially strengthen procedural protections for builders while narrowing the scope of recoverable construction defect claims. If enacted, the legislation would affect virtually every stage of a construction defect dispute- from the initial notice of claim through litigation and settlement- and would introduce an entirely new certification process for newly constructed condominium projects. This article details some of the most significant proposed changes. Higher Burden for Construction Defect Plaintiffs Perhaps the most consequential change is the bill's modification of the proof required to establish liability. current law generally requires a claimant to demonstrate the residence fails to satisfy one of the statutory performance standards established under the Right to Repair Act. AB1903 would instead require claimants to establish three separate elements:

• A violation of an applicable statutory performance standard;
• The violation caused appreciable, present, non-speculative physical damage to another building component; and
• The violation resulted from the original construction.

Reprinted courtesy of Thomas D. Fama, Wood Smith Henning Berman and Andrew J. Mallon, Wood Smith Henning Berman Mr. Fama may be contacted at tfama@wshblaw.com Mr. Mallon may be contacted at amallon@wshblaw.com Read the full story...

---