SILVER LAKE KANSAS CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Vacant Building Negates Coverage for Broken Pipe

September 01, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Michigan Court of Appeals found the insured was not covered for water damage because the commercial space was left vacant. Cherry Hill Recreation Center, Inc. v. Conifer Ins Co., 2026 Mich, App. LEXIS 5099 (Mich Ct. App. June 18, 2026). Alan Abbas purchased a bowling alley. Due to the onset of the COVID-19 pandemic and executive orders issued by the governor, Abbas was unable to operate the bowling center for several months. During the winter, Abbas allowed the thermostat to drop significantly, with the building expected to be around 43 degrees Fahrenheit. He later admitted the sprinkler system’s pipes were not protected against freezing. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Conditional Payment Bond Consideration-Make Sure There Is Pay-If-Paid Provision

June 29, 2026 — David Adelstein - Florida Construction Legal Updates
If a general contractor is going to have a conditional payment bond, it needs to ensure it subcontracts contain pay-if-paid or pay-when-paid provisions. This conditional payment language in subcontracts is the general contractor’s defense that it doesn’t have to pay a subcontractor UNTIL owner has paid the general contractor for the subcontractor’s work. The general contractor (and the surety) can look at the conditional payment bond with the s. 713.245 legend stamped on its face designating the conditional nature of the bond, and assume the conditional structure is locked in against the bond: no payment from the owner, no obligation to the subcontractors under the bond. But what happens when the subcontracts contain no express conditional payment language despite having a valid conditional payment bond? Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Over 50 Lewis Brisbois Attorneys Recognized in 7th Edition of Best Lawyers: Ones to Watch in America

September 01, 2026 — Lewis Brisbois
56 Lewis Brisbois attorneys across 26 offices have been named to the 7th edition of “Best Lawyers: Ones to Watch in America.” Congratulations to the following attorneys on this recognition! You can see the full list of Lewis Brisbois attorneys named to Best Lawyers' 33rd edition of The Best Lawyers in America here. Akron, OH

• Partner Meleah M. Skillern - Commercial Litigation

Atlanta, GA

• Partner Catherine Crawley - Personal Injury Litigation – Defendants; and Transportation Law
• Associate Davis Lackey - Insurance Law; and Personal Injury Litigation – Defendants

Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Communication Gaps Can Cost Construction Firms in the Data Center Boom

June 02, 2026 — Mike Lewis - Construction Executive
The data center construction boom is transforming the construction industry at a historic pace. Fueled by cloud computing, artificial intelligence and relentless demand for digital infrastructure, data centers have become one of the fastest-growing project types in the built environment. Billions of dollars are flowing into new facilities and expansions, creating unprecedented opportunities for construction firms positioned to deliver reliably. But opportunity alone does not guarantee success. As competition intensifies, communication failures and poor information management are emerging as some of the most common (and costly) reasons firms lose margins, miss deadlines or fail to secure repeat work. In data center construction, where schedules are compressed and tolerance for error is minimal, even small breakdowns in communication can have outsized consequences. Reprinted courtesy of Mike Lewis, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Lost in Translation: AEC Tech’s Missing Role

May 12, 2026 — Aarni Heiskanen - AEC Business
I once visited a construction site where the contractor’s headquarters had commissioned a tech company to build an on-site quality-inspection application. The developer had admitted to the site engineer that they had never set foot on a construction site before. The engineer showed me what he was actually using: his own phone camera and an Excel sheet. The new app did not map to how work actually happened on site. This is not an isolated story. The vendor builds something technically coherent but operationally disconnected. The client, somewhere up the chain, had fallen in love with the idea of the solution before anyone had built an honest business case for it. The result is a tool that gets demonstrated at a board meeting but isn’t used in the field. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Sausage-Making Often Relies on the Good Sense of the Chef Rather than the Recipe

June 23, 2026 — Garret D. Murai - California Construction Law Blog
Even for lawyers, the rules governing litigation can get complex and convoluted. Does something need to be filed? What needs to be filed? When is the deadline for filing? Simple questions with not always with straightforward answers. This was the case in R & J Sheet Metal, Inc. v. W.E. O’Neil Construction Co. of California, 111 Cal.App.5th 878 (2025), which involved sheet metal panels lost when they fell into the Port of Long Beach harbor. Read the full story...
Reprinted courtesy of Garret D. Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Congratulations to BWB&O’s Orange County Team for Securing a Strong MSJ Result in a Residential Gas Explosion Matter!

May 14, 2026 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Huge Congratulations to Partner Kevin Wheeler and Associate Lindsey Wells for securing a strong result on a Motion for Summary Judgment / Summary Adjudication filed on behalf of their client, the City of Murrieta. This was a complex, multi-party matter arising from a residential gas leak and explosion, where Plaintiffs alleged the City and MFPD failed to properly respond to the incident. After multiple complaints were consolidated and extensive defense work narrowed the case, eighteen plaintiffs remained asserting five causes of action against the City, prompting a comprehensive MSJ/MSA targeting liability, causation, and damages. The Court’s ruling reflects a significant win, particularly on the immunity framework. The Court eliminated the core negligence and assumed-duty claims arising from fire protection and emergency response activities. It further disposed of the misrepresentation and public nuisance claims. At the end of the day, three plaintiffs were dismissed entirely for failure to comply with Government Claims Act requirements, further reducing the scope of the case. While the dangerous condition claim remains, it does so in a very limited posture. Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

---