Berkshire Massachusetts Construction Expert Witness Directory

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Consider The Limited Warranty from Your Homebuilder

July 06, 2026 — David Adelstein - Florida Construction Legal Updates
When purchasing a home from a homebuilder, there is an important consideration when it comes to the limited warranty you receive around the time you close on the home. That limited warranty likely includes an arbitration provision requiring you to arbitrate your disputes, such as construction defect claims, against the homebuilder. That arbitration provision will most likely include all claims, including statutory claims (such as a statutory violation of a building code claim), requiring you to arbitrate, as opposed to litigate, your disputes against the homebuilder. This is an important consideration. If the arbitration provision does not allow you to arbitrate all of your claims, and eliminates your rights to legitimate statutory claims, the arbitration provision could be unenforceable. By way of example, in a residential construction defect dispute, Anderson v. Taylor Morrison of Florida, Inc., 223 So.3d 1088 (Fla. 2d DCA 2017), the appeal turned on whether the arbitration provision in the homebuilder’s limited warranty was valid. The homeowners took possession of their home in 2009. In 2015, the homeowners served a Florida Statutes Chapter 558 notice of construction defects that included a statutory violation of a building code claim under Florida Statute §553.84. The limited warranty included an arbitration provision that specified it was the “exclusive remedy” for all disputes arising out of or related to the warranty or issues with the home and property. When read together with the warranty’s disclaimer that precluded claims not covered by the warranty “whether in contract, tort, or otherwise,” the statutory building code violation claim could not be remedied through arbitration because it fell outside the warranty’s coverage. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Kahana Feld Announces Key Partner Additions Coast to Coast

June 22, 2026 — Kahana Feld
IRVINE, CA – June 10, 2026 – Kahana Feld is pleased to announce Yvette Davis, Evan Kalooky, Beth Obra-White, Sean Paden, Michael Parme, Jeffrey Schmid, and Julieanne Yanez have joined the firm as partners. Four of these partners are joining the San Diego office, which further strengthens the firm’s General Liability and Construction Litigation practices and enhances Kahana Feld’s ability to serve clients across a broad range of complex matters in the region. Read the full story...
Reprinted courtesy of Kahana Feld

Sixth Circuit Revives Builder’s Risk Coverage, Refusing to Let Insurer Escape on a Technicality

July 27, 2026 — Kevin V. Small & Adriana A. Perez - Hunton Insurance Recovery Blog
In 3371 Reading, LLC v. Liberty Mutual Group, the Sixth Circuit did something courts do not always do in coverage disputes: it refused to let an insurer avoid liability based on a technical policy condition that could never actually be satisfied. The decision is a straightforward reminder of two core principles. First, policies must be interpreted from the standpoint of a reasonably prudent insured. Second, hyper-technical conditions cannot be used to deny coverage where compliance is never possible. Reprinted courtesy of Kevin V. Small, Hunton Andrews Kurth LLP and Adriana A. Perez, Hunton Andrews Kurth LLP Mr. Small may be contacted at ksmall@hunton.com Ms. Perez may be contacted at pereza@hunton.com Read the full story...

That’s a Wrap! Pennsylvania Court Holds Arbitration Clause in Online Agreement Unenforceable

May 14, 2026 — Gus Sara - The Subrogation Strategist
In Duffy v. Tatum, 2026 Pa. Super. LEXIS 112, 2026 PA Super 41, the Superior Court of Pennsylvania (Superior Court) considered whether an arbitration provision contained in the online Terms of Service on the defendant’s website were enforceable. The plaintiff, Daniel Duffy (Duffy), visited the website of defendant, Dolly, Inc. (Dolly), to purchase moving services. Duffy selected the number of movers, items to be moved and the type of vehicle needed. To complete the booking, the website required Duffy to checkmark a box labeled “By checking this box I accept the Dolly Terms of Service.” Duffy did not have to open the link or scroll to the bottom of the agreement before being able to click on the checkmark box. The Terms of Service included an arbitration provision requiring that any dispute related to the moving services to be resolved by arbitration in accordance with the American Arbitration Association. The Terms of Service did not include any statement that the user was waiving the right to a jury trial. The Superior Court found the internet Terms of Service unenforceable. During the moving process, an accident occurred and injured Duffy. In May 2024, Duffy and his wife sued Dolly and other related entities alleging negligence and loss of consortium. Dolly filed preliminary objections alleging that the parties agreed to alternative dispute resolution. The lower court overruled the preliminary objections, finding that Dolly’s website did not provide reasonably obvious notice of its Terms of Service to Duffy and, as such, Duffy never agreed to waive his constructional right to a jury trial. Dolly filed an appeal to the Superior Court. Read the full story...
Reprinted courtesy of Gus Sara, White and Williams LLP
Mr. Sara may be contacted at sarag@whiteandwilliams.com

Ahlers Cressman & Sleight PLLC Recognized by Best Lawyers 2027

September 28, 2026 — Ahlers Cressman & Sleight PLLC
Continuing the trend from last year, Ahlers Cressman & Sleight PLLC is excited to announce that thirteen members of our firm have received recognition from Best Lawyers® in America for 2027. The Best Lawyers in America® has been an annual publication since 1983 and focuses on the top legal talent across the United States and the globe. Through its rankings, Best Lawyers® provides a comprehensive guide to legal representation for individuals and businesses alike. Over time, Best Lawyers® has been recognized as one of the leading publications for attorney achievements and references. Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

“The Superintendent Told Us to Do It:” Why Verbal Approval May Not Be Enough

June 02, 2026 — Andrew Lintner - Colorado Construction Litigation Blog
In construction defect litigation, one scenario appears repeatedly: a subcontractor installs work in a manner that differs from the plans, specifications, manufacturer instructions, or industry standards after being verbally directed to do so by the general contractor, superintendent, architect, or owner’s representative. At the time, the decision may seem minor. The project is moving quickly, the field team wants to maintain progress, and nobody wants to stop working over what appears to be a small issue. The subcontractor may trust the superintendent or project manager and assume the conversation will be remembered later if questions arise. Years later, however, when the project experiences problems, the people involved may deny the conversation occurred, remember it differently, or simply no longer remember the project. Without written documentation, the subcontractor can find itself defending claims for defective work, even though it performed the installation exactly as directed. Read the full story...
Reprinted courtesy of Andrew Lintner, Higgins, Hopkins, McLain & Roswell, LLC
Mr. Lintner may be contacted at alintner@hhmrlaw.com

Partner Bryan Stofferahn and Our Walnut Creek Team Secure Summary Judgment in a $28 Million Premises Liability Case!

September 15, 2026 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
BWB&O is proud to announce that Partner Bryan Stofferahn and the Walnut Creek Team secured a Summary Judgment on behalf of the firm’s clients, resulting in a complete dismissal of a negligence and premises liability claim. Plaintiff, a teenager, was riding his bicycle on private commercial property when he was struck by a vehicle. Plaintiff was in a coma for 6 weeks and developed major neurocognitive dysfunction from a traumatic brain injury. BWB&O’s clients are a commercial property owner and property management company, who Plaintiff contended were liable for his injuries based on the design, condition, operation, and management of the premises. Plaintiff had demanded $28 million in settlement of the claims against all defendants. Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara, LLP

BERKSHIRE MASSACHUSETTS CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES