Opheim Montana Construction Expert Witness Directory

Insured General Contractor Prevails on Motion for Summary Judgment to Establish Builder’s Risk Coverage

July 06, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The general contractor’s motion for partial summary judgment successfully established that damage to footings in place before the policy period was covered after the collapse of a building. Big D Builders, Inc. v. Am Zurich Ins. Co., 2026 U.S. Dist. LEXIS 72012 (D. Idaho March 31, 2026). Big D was the general contractor for building a new airplane hangar by erecting a 38,000 square foot structure. Before Big D began construction, the site of the hangar did not contain any pre-existing structures or buildings. Before completion of the hangar, it collapsed and caused extensive property damage. The builder’s risk policy issued by Zurich covered certain aspects of the construction project for the policy period December 28, 2023, to December 28, 2024. Zurich accepted coverage for most of the damage but not for damage to footings and columns installed prior to the start date of the policy. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Robotics Works Where Variation Ends

August 11, 2026 — Aarni Heiskanen - AEC Business
BuiltWorlds published its 2026 Robotics Top 50 this summer, and the list is genuinely wide. Fifty solutions across nine categories, from 3D printing and prefabricated component manufacturing to earthmoving, demolition, material transport, layout, installation, inspection, and drilling. The honorees come from sixteen countries. It looks like robotics has finally spread across the whole project lifecycle. However, having vendors in nine categories does not mean that contractors are robotizing their work en masse. Zacua Ventures, in its 2026 construction robotics report, estimates that on-site robotics accounted for less than 0.03% of global construction spending in 2025. Zacua says: “That is not a failed market. It is a market at the beginning of an adoption S-curve”, while warning that its estimates rest on private vendor data and may be high if vendors overstate how widely their machines are deployed. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

U.S. Supreme Court Decision May Negate State Law Requirement to File a Certificate of Merit with the Complaint in a Federal Action Against a Design Professional

April 27, 2026 — Christopher Olsen & Phillip Boldt - ConsensusDocs
To deter frivolous and unfounded claims against design professionals, states throughout the country have enacted statutes which generally require litigants to furnish a formal certification of merit (“COM”) from a qualified expert or face potential dismissal of their lawsuit. These COM statutes can impose a significant front-end burden on claimants who must pay an expert to review project records, interview the project team, and prepare a formal report before the lawsuit can be filed—often regardless of the amount in controversy. However, in light of a recent U.S. Supreme Court decision in a medical malpractice case, most, if not all of these statutes, may no longer be enforceable in federal court. This article examines the recent decision in Berk v. Choy, 146 S. Ct. 546 (2026), the decisions thus far which have applied Berk to invalidate COM statutes, and other categories of statutes applicable to the construction industry which may face a similar fate. The U.S. Supreme Court Decision (Berk v. Choy) In Berk, the plaintiff, Harold Berk, sued a doctor for medical malpractice under Delaware law in Delaware federal court. 146 S. Ct. at 551. Under Del. Code, Tit. 18, § 6853(a)(1), an affidavit of merit (like a COM) must accompany a complaint alleging medical malpractice. Id. Berk failed to include an affidavit of merit with his complaint. Id. at 552. Applying Delaware state law, the federal court dismissed Berk’s medical malpractice claim. Berk appealed to the Third Circuit, arguing that the affidavit of merit required by § 6853(a)(1) is unenforceable in federal court because it is more onerous than the Federal Rules of Civil Procedure. The Third Circuit affirmed the District Court’s ruling, finding § 6853(a)(1) enforceable in federal court. Reprinted courtesy of Christopher Olsen, Peckar & Abramson, P.C. and Phillip Boldt, Peckar & Abramson, P.C. Mr. Olsen may be contacted at colsen@pecklaw.com Mr. Boldt may be contacted at pboldt@pecklaw.com Read the full story...

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insurer Granted Summary Judgment on Claim for Roof Damage Caused by Windstorm

May 26, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The insurer successfully moved for summary judgment, eliminating the insured’s claim for roof damage due to windstorm. Mulas v. Westchester Surplus Lines Ins. Co., 2026 U.S. Dist. LEXIS 20537 (Jan. 30, 2026). The insureds’ commercial property sustained windstorm damage during Hurricane Ian. Westchester denied the claim. The insureds believed Westchester wrongfully denied coverage for roof damage and various interior damage to property. The insureds also argued that Westchester’s actual cash value (ACV) payment did not reflect the fully insured loss. The insureds sued and Westchester moved for summary judgment. Westchester argued the roof damage was not covered because Hurricane Ian did not cause the damage. Westchester hired an engineer who determined the roof damage was not caused by wind from Hurricane Ian. Westchester pointed out that the insureds’ expert also found no wind damage on the roof. The insureds offered no other evidence suggesting the hurricane caused roof damage. Therefore, the insureds could not show that Westchester breached the policy by denying coverage. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

How AEC Firms Move AI Beyond the Pilot

July 27, 2026 — Aarni Heiskanen - AEC Business
Most AEC firms can run an AI pilot, but few can scale it. Enthusiasm for a first experiment rarely extends beyond the pilot team, leaving the pilot as an isolated win that never changes how the company works. In a recent AEC Business Podcast episode, Adeline Chan, CEO and co-founder of Hong Kong-based AAL Innovation, explained why that gap exists and what separates the firms that close it from those that stall. The Pilot Mindset that Holds Construction Back Adeline draws a sharp contrast between finance and construction. Banks cannot afford to fall behind their competitors, so they pilot constantly, sometimes running hundreds of proof-of-concept teams in parallel and letting them compete internally to identify the approach that works. The winning concept becomes the standard and scales across the organization, and the return on investment is measured in undeniable numbers. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Contractor Dispute Resolution Framework and Prevention

July 06, 2026 — Construction Executive
WHAT DEFINES A CONTRACTOR DISPUTE RESOLUTION FRAMEWORK A contractor dispute resolution framework is a structured system of contractual terms, governance processes and escalation pathways designed to prevent, manage and resolve conflicts between contracting parties with minimal disruption to cost, schedule and performance. The framework operates as both a preventive control and a corrective mechanism. Preventive elements establish clarity in scope, expectations and accountability before work begins. Corrective elements define how disagreements are identified, documented, escalated and resolved once they arise. Reprinted courtesy of Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Late Notice Bars Insured’s Claim for Wind Damage

June 29, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The court found that a six-month delay in reporting damage from wind did not comply with the policy’s notice requirements. Touchmark Hotel Group, LLC v. Mt. Hawley Ins. Co., 2026 U.S. Dist. LEXIS 61910 (S.D. N. Y. March 24, 2026). A storm caused damage to Touchstone’s hotel on January 4, 2023. Touchstone’s corporate representative, Rohit Patel, testified that he was not at the property on the day of the storm. In a telephone call the next day, the manager of the property reported to Patel that he observed detached shingles from the roof the hotel in the parking lot. Patel testified that he did not file a claim at that time because Touchmark’s employees did not detect any water leakage in the building and because he did not believe that the cost of the damage from the storm would exceed the policy’s deductible. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

OPHEIM MONTANA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES