Neligh Nebraska Construction Expert Witness Directory

We Won’t Permit That Excuse!

June 23, 2026 — Curt Martin & Richard Eiszner - ConsensusDocs
A Texas appellate court recently ruled that a building permit wasn’t a condition precedent for a construction project. That caught our attention. Can you build a commercial project without a permit? But as we read the case, we see the court’s reasoning. And it reminds us of an important legal principle that should inform our contract drafting and negotiation. The case was a civil suit brought by the project owner against its tenant improvement contractor for work on a medical spa. The owner claimed that the contractor didn’t perform the work properly and didn’t finish construction. The contractor argued that delays and problems were caused by the owner, alleging numerous failures, including the owner’s failure to secure a building permit. Reprinted courtesy of Curt Martin, Peckar & Abramson, P.C. and Richard Eiszner, Peckar & Abramson, P.C. Mr. Martin may be contacted at cmartin@pecklaw.com Mr. Eiszner may be contacted at reiszner@pecklaw.com Read the full story...

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

GRSM Attorneys Recognized in The Best Lawyers in America® 2027

August 24, 2026 — Gordon Rees Scully Mansukhani
Gordon Rees Scully Mansukhani is pleased to announce that 183 of its attorneys were listed in The Best Lawyers in America© 2027 Edition, six of whom received “Lawyer of the Year” recognitions. Additionally, 49 GRSM attorneys were recognized in Best Lawyers: Ones to Watch 2027. Best Lawyers lists are compiled based on peer-review evaluations. For the 2027 edition of The Best Lawyers in America®, results were determined using millions of confidential attorney evaluations. Ones to Watch adopts the same peer-review methodology. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

Trend Continues Where Unlicensed Contractors Have No Recourse

July 13, 2026 — David Adelstein - Florida Construction Legal Updates
There’s been a recent trend in Florida case law that has figuratively “killed” unlicensed contractors. Here’s another one. The moral to this trend and case is simple: make sure you have the proper licenses prior to serving as a contractor under Florida law. Trying to be cute, as seemed to be the situation in this case with a creative argument, is not an argument that will carry the day and your resources will be devoted to being creative versus the ultimate merits of the dispute. In Ramindesign, LLC v. Skarzynski, 2026 WL 1649571 (S.D.Fla. 2026) an owner of real property hired a company to design and construct a spec home on the property. The company and its owner were NOT licensed contractors. The contract stated the company was serving as a “spec developer” and referred to it as the contractor throughout the contract. Other than this, the contract was set up as a cost plus a fee. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

GRSM Ranked Among Top 5 Construction Law Firms by Construction Executive

September 21, 2026 — Gordon Rees Scully Mansukhani
Gordon Rees Scully Mansukhani has been ranked the No. 5 construction law firm in the nation by Construction Executive in the magazine’s 2026 ranking of The Top 50 Construction Law Firms™. “Being named in the top five underscores the talent, experience, and nationwide capabilities of our construction team,” said Allen Estes III and Angela Richie, Chairs of GRSM’s Construction practice. “We are honored to serve as trusted counsel to clients across the construction industry and remain committed to delivering strategic solutions that help them achieve their business and project objectives.” In addition to this ranking, GRSM Construction practice group Co-Chairs Allen Estes and Angela Richie were featured in “Executive Insights 2026: Leaders in Construction Law,” where they shared insights on key risks to consider before signing construction contracts and discussed strategies for managing material cost volatility, supply-chain disruptions, and project delays. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

Building the Research and Healthcare Facilities of Tomorrow Without Impacting the Progress of Today

August 16, 2026 — Jason Tobias - Construction Executive
Research labs run experiments that can’t be paused. Hospitals treat patients around the clock. Yet these same facilities constantly need upgrades—new infrastructure, modernized systems, renovated spaces—to meet the demands of twenty-first century science and medicine. The challenge for construction teams isn’t just building. It’s building without ever turning the lights off. This unique dynamic creates an environment where construction activities are happening adjacent to sensitive testing and treatment, a complex setting where disruptions can have serious consequences. Skanska continues to successfully navigate these challenges across multiple sectors, including from occupied lab space at the North Carolina Department of Environmental Quality’s (NCDEQ) Reedy Creek Laboratory in Raleigh to hospital corridors alongside staff and patients in various hospital locations across the country. Reprinted courtesy of Jason Tobias, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Consider The Limited Warranty from Your Homebuilder

July 06, 2026 — David Adelstein - Florida Construction Legal Updates
When purchasing a home from a homebuilder, there is an important consideration when it comes to the limited warranty you receive around the time you close on the home. That limited warranty likely includes an arbitration provision requiring you to arbitrate your disputes, such as construction defect claims, against the homebuilder. That arbitration provision will most likely include all claims, including statutory claims (such as a statutory violation of a building code claim), requiring you to arbitrate, as opposed to litigate, your disputes against the homebuilder. This is an important consideration. If the arbitration provision does not allow you to arbitrate all of your claims, and eliminates your rights to legitimate statutory claims, the arbitration provision could be unenforceable. By way of example, in a residential construction defect dispute, Anderson v. Taylor Morrison of Florida, Inc., 223 So.3d 1088 (Fla. 2d DCA 2017), the appeal turned on whether the arbitration provision in the homebuilder’s limited warranty was valid. The homeowners took possession of their home in 2009. In 2015, the homeowners served a Florida Statutes Chapter 558 notice of construction defects that included a statutory violation of a building code claim under Florida Statute §553.84. The limited warranty included an arbitration provision that specified it was the “exclusive remedy” for all disputes arising out of or related to the warranty or issues with the home and property. When read together with the warranty’s disclaimer that precluded claims not covered by the warranty “whether in contract, tort, or otherwise,” the statutory building code violation claim could not be remedied through arbitration because it fell outside the warranty’s coverage. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Modular Construction’s Hidden Risk: Where Things Go Wrong Between the Factory and the Field

June 15, 2026 — Jack Mayo - ConsensusDocs
Introduction As modular and prefabricated construction methods are increasingly adopted, so too are the potential challenges that come with them. The appeal is straightforward: faster timelines, controlled fabrication environments, and reduced on-site labor demands. But the risks that accompany these benefits are often less clear—and, in many cases, poorly defined. For example, what happens when a prefabricated component is delayed past its installation window? Who is responsible for a defect discovered inside a sealed, installed module? What happens to warranty obligations when a prefabricated component must be modified on site? Read the full story...
Reprinted courtesy of Jack Mayo, Jones Walker LLP
Mr. Mayo may be contacted at jmayo@joneswalker.com

NELIGH NEBRASKA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES