Louisburg North Carolina Construction Expert Witness Directory

The Most Expensive Signature to Not Get: Why Change Orders Matter

August 16, 2026 — Kathryne E. Baldwin - Wilke Fleury
George Bernard Shaw has a quote we use a lot in my family: “The single biggest problem in communication is the illusion that it has taken place.” This is pertinent to contractors and homeowners alike because the cost of failing to get proper signatures on documents like construction contracts, and particularly, change orders, is heavy. Both contractors and homeowners are in the same boat as far as wanting to complete a job as swiftly as possible: contractors go on to their next job and homeowners can return to peace in their home. This is prime territory for either party to suggest the work be completed today and the contract or change order executed tomorrow, or even later. However, without a contract, there is no memorialization of the communication between the parties, which can lead to confusion and missed expectations on both sides. Construction plans are rarely as neat and tidy as they originally seem to be. A contractor may uncover unforeseen conditions, an owner may request additional work or changes that require additional work, or weather interferes with project schedules or the work itself. Unfortunately, the signature that never gets collected can become one of the most expensive omissions on a project – for both sides. Read the full story...
Reprinted courtesy of Kathryne E. Baldwin, Wilke Fleury
Ms. Baldwin may be contacted at kbaldwin@wilkefleury.com

Meet BWB&O’s 2027 Super Lawyers Southwest Rising Stars, Ryan Leibel!

November 09, 2026 — Dolores Montoya - Bremer Whyte Brown & O’Meara, LLP
Please join us in congratulating BWB&O’s Arizona Associate Ryan Leibel on being named to the 2027 Super Lawyers Southwest Rising Stars list! Ryan is being recognized for his work in General Litigation, marking an exciting professional milestone and reflecting his dedication to the practice of law. Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara, LLP

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Court Rules Insurer AIG Can't Claw Back $50M Storm Payout From Turner

October 20, 2026 — Richard Korman - Engineering News-Record
A Delaware court judge ruled earlier this month that insurer AIG cannot claw back $50 million from Turner Construction for two insurance claim payouts it has made to New York University's Langone Medical Center. The dispute relates to the 2012 flooding of the university's Manhattan hospital center during Superstorm Sandy in October 2012. Read the full story...
Reprinted courtesy of Richard Korman, Engineering News-Record
Mr. Korman may be contacted at kormanr@enr.com

Differing Site Conditions Claim Requires a Misrepresentation

May 14, 2026 — David Adelstein - Florida Construction Legal Updates
If you are entertaining a differing site conditions claim, consider this Third District Court of Appeals case from the mid-90s. In Hendry Corp. v. Metropolitan Dade County, 648 So.2d 140 (Fla. 3d DCA 1995), a contractor was hired by Dade County to demolish the old Rickenbacker Causeway in Miami. The original 1941 plans of the causeway were made available to contractors. The lowest bidding contractor that was awarded the project based its bid “on its conclusion that the pilings supporting the old bridge were made of concrete.” Hendry, supra at 141. The contractor based this conclusion on the original plans, its visual observation, and experience. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Real Estate & Construction News Roundup (7/8/26) – Data Centers Negotiate Flexibility for Speed, Hotel Deal Activities Focus on Luxury, and DC Sues Apartment Owners

July 20, 2026 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, rail projects gain steam across the U.S., AI optimizes building operations, a modular approach speeds data center construction, and more!

Hyperscalers want their data centers online, and utilities want to provide interconnections, but both are still looking for common operating guidelines. (Herman K. Trabish, Construction Dive)
Contractors are taking advantage of multibillion-dollar train and transit contracts, even as funding challenges create hurdles for project execution. (Matthew Thibault, Construction Dive)
Although hospitality and leisure M&A deal volume was down 2.5% in the first half of 2026 compared to the prior six months, investors are concentrating on the upper end of the market, including luxury hotels, wellness resorts and gaming, or “data-rich,” platforms. (Noor Adatia, Hotel Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

A Permitting Base Checklist for Data Centers and Power Plants

June 02, 2026 — Michael S. McDonough, Stephen J. Humes & Stacey C. Wright - Gravel2Gavel Construction & Real Estate Law Blog
There is a lot of talk these days about “license to operate” for data centers, meaning management of the relationships with stakeholders and broader communities concerning both the benefits and adverse consequences of locating a facility in a particular locale. Here, we are speaking of “license to operate” more literally—namely, the legal and regulatory permitting and approval requirements for a privately owned data center whether by itself or colocated with a power generating plant. Our Base Checklist includes generally and potentially applicable permitting requirements for development and operation, using California as an example. (Taking legal authority Frank Sinatra out of context, “If you can make it there, you can make it anywhere.”) The actual requirements for a given facility would depend, in part, on local law, including planning and zoning laws and plans, and the environment of the site. Just as examples, additional permitting and mitigation requirements might apply if sensitive receptors are located nearby (e.g., noise mitigation for residential dwellings), if sensitive and protected biological resources (e.g., jurisdictional waters and/or protected species) would be impacted, or if the present or former land uses require additional measures (e.g., hazardous materials remediation, mitigation for conversion of prime farmland, or protection of cultural resources). The scope of permit requirements would ultimately be determined by the applicable regulatory agencies and by the lead and responsible agencies under the applicable state environmental land use regime—in our reference case here, the California Environmental Quality Act (CEQA). Reprinted courtesy of Michael S. McDonough, Pillsbury, Stephen J. Humes, Pillsbury and Stacey C. Wright, Pillsbury Mr. McDonough may be contacted at michael.mcdonough@pillsburylaw.com Mr. Humes may be contacted at stephen.humes@pillsburylaw.com Ms. Wright may be contacted at stephen.humes@pillsburylaw.com Read the full story...

Pay-If-Paid: What You Need to Know Before Signing on the Dotted Line

August 03, 2026 — Christian Fernandez & Matthew Racioppo - Snell & Wilmer
Buried deep in the fine print of a subcontract, a pay-if-paid clause may be looming. If you are a subcontractor or supplier, misreading these clauses can put your cash flow at risk. If you are an owner or general contractor, drafting them incorrectly can leave you with obligations you never intended — or unenforceable protections you were counting on. It is more important than ever to understand when pay-if-paid clauses hold up and when they do not, as well as recent litigation and drafting trends. Whether you are negotiating a new agreement, reviewing your standard form contracts, or staring down a payment dispute, understanding how Arizona law treats pay-if-paid clauses is essential. In this article, we break down key considerations, walk through the legal standards Arizona courts apply, and offer practical tips to consider to help you protect your payment rights on the next project. Reprinted courtesy of Christian Fernandez, Snell & Wilmer and Matthew Racioppo, Snell & Wilmer Mr. Fernandez may be contacted at cfernandez@swlaw.com Mr. Racioppo may be contacted at mracioppo@swlaw.com Read the full story...

LOUISBURG NORTH CAROLINA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES