TAHLEQUAH OKLAHOMA CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Actual Controversy Without Actual Exhaustion: California Supreme Court Allows Declaratory Relief and Bad Faith Claims Against Excess Insurers

August 24, 2026 — Kyle A. Rudolph - Saxe Doernberger & Vita, P.C.
California courts were previously split on the issue of whether an insured may bring declaratory relief claims against excess insurers prior to the exhaustion of underlying insurance. Some California courts held that the actual exhaustion of underlying insurance was necessary, whereas other courts allowed for these types of claims to proceed.[1] Recently, the California Supreme Court addressed this split of authority and, in doing so, handed down a significant win for policyholders. In Fox Paine & Company, LLC, et al. v. Twin City Fire Insurance Company et al., the Court held that insureds may proceed with bringing forth viable declaratory relief and bad faith claims against excess insurers prior to the exhaustion of underlying insurance.[2] A summary of the Court’s opinion is provided below. Read the full story...
Reprinted courtesy of Kyle A. Rudolph, Saxe Doernberger & Vita, P.C.
Mr. Rudolph may be contacted at KRudolph@sdvlaw.com

---

Hidden Risks Behind Today’s Stadium Construction Boom

July 20, 2026 — Thomas Strong, Andrew Canning & Marc Gnesin - Construction Executive
After a decade-plus lull, professional sports leagues, universities and municipalities are once again spending heavily on new stadiums and major renovations. In the NFL alone, multiple marquee projects are underway or planned, representing more than $10 billion in facilities and mixed-use entertainment districts, rivaling or exceeding the scale of development during the last stadium-build cycle of the early 2000s. Beneath the excitement of architectural ambition and civic pride lies a risk landscape that has fundamentally changed since the last wave of stadium construction. Teams, cities and contractors that rely on outdated assumptions may find themselves exposed to cost overruns, schedule delays and liabilities that are far more difficult to unwind once construction is underway. Reprinted courtesy of Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Over 50 Lewis Brisbois Attorneys Recognized in 7th Edition of Best Lawyers: Ones to Watch in America

September 01, 2026 — Lewis Brisbois
56 Lewis Brisbois attorneys across 26 offices have been named to the 7th edition of “Best Lawyers: Ones to Watch in America.” Congratulations to the following attorneys on this recognition! You can see the full list of Lewis Brisbois attorneys named to Best Lawyers' 33rd edition of The Best Lawyers in America here. Akron, OH

• Partner Meleah M. Skillern - Commercial Litigation

Atlanta, GA

• Partner Catherine Crawley - Personal Injury Litigation – Defendants; and Transportation Law
• Associate Davis Lackey - Insurance Law; and Personal Injury Litigation – Defendants

Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Preventing Common and Costly Water Intrusion Events in Construction

July 13, 2026 — Andrew Swift - Construction Executive
Water leaking into a building is a leading cause of damage and loss in the construction industry. On one jobsite, heavy rains flooded a sub-basement, damaging a new electrical transformer—all because a roof drain was not property connected. On another jobsite, a drinking-fountain supply line broke in a multistory building that was undergoing renovation, causing water to run—undetected—for an entire weekend, resulting in water damage to all lower floors, where construction had been finished. Those loss scenarios could have been prevented with a comprehensive and effective water damage prevention plan (WDPP). This includes routine site inspections to identify uncontrolled water damage exposures and basic maintenance to make sure drains are clean of debris and divert them to a catch basin or low point away from the building. An effective WDPP plan also incorporates technology such as backflow preventers on sewer connections and water sensing technology to monitor the most vulnerable exposures. Reprinted courtesy of Andrew Swift, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Two Important Points Regarding the Miller Act

September 15, 2026 — David Adelstein - Florida Construction Legal Updates
A recent Miller Act case, U.S. f/u/b/o Boundless Management Outsourcing Group, LLC v. Endurance Assurance Corp, 2026 WL 2241491 (D. Puerto Rico 2026), confirms two important points when it comes to the Miller Act. In this case, a subcontractor pursued a Miller Act payment bond lawsuit more than one year after its work was finished. The subcontractor also asserted a claim against the federal government. The lawsuit was dismissed. Below are two takeaway points to consider if you are dealing with a Miller Act payment bond lawsuit. First, as it relates the claim against the federal government, the federal district court followed authority that held that the Miller Act does NOT include a waiver of sovereign immunity against the federal government. “[T]he Court does not identify any clear language in the Miller Act expressly waiving the United States or its agencies’ sovereign immunity.” Endurance Assurance Corp., supra at *3. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Federal Bid Protest Standard of Review and Disparate Treatment with Ratings

August 16, 2026 — David Adelstein - Florida Construction Legal Updates
A recent decision out of the Federal Claims Court explains the post-award bid protest standard of review. In Massman Construction Co. v. U.S., 2026 WL 1971985 (Fed.Cl. 2026), a protestor brought a post-award bid protest after the Army Corps of Engineers awarded the contract to another contractor. The protestor argued that the Army Corps (government) acted irrational in its evaluation through disparate treatment. The Court of Federal Claims agreed and remanded for the Army Corps to “either justify this disparity or explain why [awardee’s] lower-priced, but technically inferior proposal provides the best value to the government.” Massman Construction, supra at *1. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Lewis Brisbois Partner and National Trial Team Member Ian B. Lane Elected President of ABOTA’s Southern New York Chapter

October 20, 2026 — Lewis Brisbois
Lewis Brisbois is pleased to announce that New York Partner Ian B. Lane, a member of the firm’s National Trial Team, has been elected president of the Southern New York Chapter of the American Board of Trial Advocates (ABOTA) for the 2027-2028 term. In this role, Mr. Lane will help lead the organization's efforts to promote excellence in trial advocacy, to foster professionalism within the legal profession, and to advance the chapter's educational, professional, and public service initiatives. Lewis Brisbois has nearly 40 ABOTA members across the country. "I am deeply honored by the confidence my colleagues have placed in me," said Mr. Lane. "ABOTA plays a vital role in preserving the right to trial by jury and promoting the highest standards of professionalism, civility, and advocacy. I look forward to working with our members to advance those goals, support the development of the next generation of trial lawyers, and strengthen the important role of the civil justice system." Read the full story...
Reprinted courtesy of Lewis Brisbois

---