MERLIN OREGON CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Wadsworth v. Regional Rail Partners — Verified Statements of Claim Under the Colorado Public Works Act

August 25, 2026 — Olivia Barden - Colorado Construction Litigation Blog
Editor’s Note: Wadsworth Revisited In August 2024, following the Colorado Court of Appeals’ decision in Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners, we published Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims. At the time, the decision warranted a significant warning to contractors and subcontractors performing public work in Colorado. The Court of Appeals concluded that Wadsworth’s verified statement of claim improperly included unliquidated delay damages and that, because the claim was excessive, Wadsworth forfeited its right to recover the amounts included in the claim. We cautioned contractors to carefully scrutinize verified statements of claim and to avoid including unliquidated damages or amounts that were not yet due and payable. The Colorado Supreme Court has now reversed that decision. Read the full story...
Reprinted courtesy of Olivia Barden, Higgins, Hopkins, McLain & Roswell, LLC

---

Snell & Wilmer’s Los Angeles Office Recognized as One of the “Best Places to Work” by the Los Angeles Business Journal

September 15, 2026 — Snell & Wilmer
LOS ANGELES – Snell & Wilmer is proud to announce that its Los Angeles office has been named one of the 2026 Best Places to Work by the Los Angeles Business Journal as part of its annual Best Places to Work awards. The recognition honors outstanding employers across the Los Angeles region that are fostering strong workplace cultures and creating positive employee experiences. Selections are based on confidential employee surveys conducted by Workforce Research Group, which evaluate organizations on leadership, corporate culture, communication, employee engagement, and other key workplace factors. “We are honored to be recognized as one of the Best Places to Work in Los Angeles,” said Joshua Schneiderman, managing partner of the firm’s Los Angeles office. “This recognition reflects the collaborative culture we have built and the dedication of our attorneys and professional staff who contribute to making our office a great place to work. We remain committed to providing opportunities for growth, fostering meaningful connections, and supporting our team members’ continued success.” Read the full story...
Reprinted courtesy of Snell & Wilmer

---

Contractor Dispute Resolution Framework and Prevention

July 06, 2026 — Construction Executive
WHAT DEFINES A CONTRACTOR DISPUTE RESOLUTION FRAMEWORK A contractor dispute resolution framework is a structured system of contractual terms, governance processes and escalation pathways designed to prevent, manage and resolve conflicts between contracting parties with minimal disruption to cost, schedule and performance. The framework operates as both a preventive control and a corrective mechanism. Preventive elements establish clarity in scope, expectations and accountability before work begins. Corrective elements define how disagreements are identified, documented, escalated and resolved once they arise. Reprinted courtesy of Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Doctrine of Substantial Performance When It Comes to Payment

July 27, 2026 — David Adelstein - Florida Construction Legal Updates
A recent non-construction case touches upon the doctrine of substantial performance when it comes to payment. In this case, a club was to make two payments to secure a rapper’s attendance. The first payment was made. The second payment was made but was a few hundred dollars short of the agreed amount. The rapper did not show up. The club claimed it substantially performed its obligations. At first glance, the argument makes sense because the second payment fell only a few hundred dollars short. But that wasn’t the case when it comes to pre-commencement payment obligations:

Substantial performance applies only when the variance from the contract terms “is inadvertent or unintentional and unimportant so that the work actually performed is substantially what was called for in the contract.” However, when one party agrees to pay the other on or before a specific date, time is of the essence, and the payor is required to pay the payee on or before that date. “There is almost always no such thing as ‘substantial performance’ of payment between commercial parties when the duty is simply the general one to pay. Payment is either made in the amount and on the date due, or it is not.”

Big Gate Records, LLC v. Washington, 51 Fla.L.Weekly D1281a (Fla. 2nd DCA 2026) (internal citations omitted).

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Nomos LLP Partner Garret Murai Recognized by Super Lawyers

July 13, 2026 — Garret D. Murai - California Construction Law Blog
Nomos LLP Partner Garret Murai has been recognized as a 2026 Northern California Super Lawyer honoree in the area of Construction Litigation. This is the thirteenth consecutive year he has been recognized by Super Lawyers. Super Lawyers, an annual listing of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and personal achievement, is limited to no more than five percent (5%) of lawyers in a state who are selected through a multiphase process that includes a statewide survey of lawyers, independent research evaluation and peer reviews by practice area. Read the full story...
Reprinted courtesy of Garret D. Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

White and Williams LLP Secures $42.4 Million Award for Ventana DBS LLC in Philadelphia Marriott Construction Litigation

July 27, 2026 — Craig O'Neill, Lindsay Liebman, Kristen Nichols Wright, Zachary Roth & William Taylor - White and Williams
White and Williams LLP's Construction and Surety Practice attorneys secured a significant victory for client Ventana DBS LLC in a complex commercial construction dispute before the Philadelphia Court of Common Pleas, Commerce Division. The trial team, led by Bill Taylor, retired Partner, and Craig O'Neill, Co-Chair of the Construction and Surety Practice Group, with support from Lindsay Liebman, Counsel, Zachary Roth, Partner, Kristen Nichols Wright, Associate, and Sue Ferrante, Legal Secretary, obtained a $42.4 million award on Ventana's claims for unpaid work, delay costs, CASPA penalties and interest, attorneys’ fees and other project-related costs arising from the construction of the Marriott W/Element Hotel Project in Philadelphia. To achieve this result, the White and Williams team managed an extensive discovery period over the course of four-years of litigation, conducted over sixty depositions, participated in court-ordered mediation and arbitration proceedings, and successfully represented Ventana during a bifurcated trial that spanned over the course of a year. Reprinted courtesy of Craig O'Neill, White and Williams, Lindsay Liebman, White and Williams, Kristen Nichols Wright, White and Williams, Zachary Roth, White and Williams and William Taylor, White and Williams Mr. O'Neill may be contacted at oneillc@whiteandwilliams.com Ms. Liebman may be contacted at liebmanl@whiteandwilliams.com Ms. Wright may be contacted at wrightk@whiteandwilliams.com Mr. Roth may be contacted at rothz@whiteandwilliams.com Mr. Taylor may be contacted at taylorw@whiteandwilliams.com Read the full story...

---

Achieving Sustainability Through Design-Build Delivery: Part I – An Overview

September 21, 2026 — Joshua M. Pruett, Jennifer L. Harris & Tiffany A. Harrod - Peckar & Abramson, P.C.
This article was written for the AGC’s Law in Brief and first appeared here. Sustainability is no longer optional. What was once a matter of public policy or corporate preference has become a regulatory mandate and is reshaping how construction projects are designed, built, and operated. This mandate is not solely figurative. Rather, states have started to follow Europe’s lead by beginning to codify sustainability requirements into regulations and law. California led the charge by adding mandatory embodied-carbon emissions regulations into CALGreen, and other states, such as New York, have introduced bills to implement similar requirements. Owners, designers, and builders must now treat sustainability not as aspirational, but as a clearly defined contract issue from the outset, particularly where the project is expected to achieve a third-party rating, meet energy or resiliency targets, qualify for incentives, or comply with evolving green building codes. In the federal public sector, construction contracts include a layered compliance framework—executive order-inspired policy, FAR-mandated clauses, and enduring statutory requirements—requiring contractors to integrate sustainability into design, material selection, and lifecycle management. Staying ahead means aligning with regulatory standards, conducting life-cycle cost analyses, and embedding sustainability into every procurement and construction decision. Reprinted courtesy of Joshua M. Pruett, Peckar & Abramson, P.C., Jennifer L. Harris, Peckar & Abramson, P.C. and Tiffany A. Harrod, Peckar & Abramson, P.C. Mr. Pruett may be contacted at jpruett@pecklaw.com Ms. Harris may be contacted at jharris@pecklaw.com Ms. Harrod may be contacted at tharrod@pecklaw.com Read the full story...

---

Presumption of Prejudice Applies to All Affirmative Defenses Regarding Insured’s Failure to Comply with Post-Loss Policy Conditions

June 23, 2026 — David Adelstein - Florida Construction Legal Updates
n a recent property insurance coverage dispute, an issue on appeal pertained to the “prejudice” jury instruction associated with the insured’s failure to comply with post-loss policy conditions. The trial court found that the prejudice only pertained to prompt notice and not other post-loss policy conditions. This was reversed on appeal as prejudice applied to ALL the post loss policy conditions that the insured failed to comply with, not just the prompt notice requirement. The prejudice presumption applies to all affirmative defenses regarding an insured’s failure to comply with post-loss policy conditions. Consider this discussion when dealing with an insurer raising prejudice as an affirmative defense to do an insured’s failure to comply with post-loss policy conditions, and the associated burdens of proof: On appeal, [the insurer] contends the trial court erred by instructing the jury that the presumption of prejudice was inapplicable to all of its post-loss obligation defenses except prompt notice. We agree. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---