Andreas Pennsylvania Construction Expert Witness Directory

We Won’t Permit That Excuse!

June 23, 2026 — Curt Martin & Richard Eiszner - ConsensusDocs
A Texas appellate court recently ruled that a building permit wasn’t a condition precedent for a construction project. That caught our attention. Can you build a commercial project without a permit? But as we read the case, we see the court’s reasoning. And it reminds us of an important legal principle that should inform our contract drafting and negotiation. The case was a civil suit brought by the project owner against its tenant improvement contractor for work on a medical spa. The owner claimed that the contractor didn’t perform the work properly and didn’t finish construction. The contractor argued that delays and problems were caused by the owner, alleging numerous failures, including the owner’s failure to secure a building permit. Reprinted courtesy of Curt Martin, Peckar & Abramson, P.C. and Richard Eiszner, Peckar & Abramson, P.C. Mr. Martin may be contacted at cmartin@pecklaw.com Mr. Eiszner may be contacted at reiszner@pecklaw.com Read the full story...

Bona Fide Dispute Defeats Violation of Prompt Payment Act

June 15, 2026 — David Adelstein - Florida Construction Legal Updates
Most, if not all, jurisdictions, including the federal government, have what is known as a “Prompt Payment Act.” The objective is to ensure prompt payment. If prompt payment is not made, the Prompt Payment Act provides for interest penalties, as well as potentially other costs such as attorney’s fees. But the thing is, it’s not as simple as untimely payment to support the recourse and interest penalties the applicable Prompt Payment Act affords. And the teeth associated with the applicable Prompt Payment Act are not as sharp as perhaps the party claiming untimely payment prefers. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Labor Shortages in Construction: Managing Legal and Operational Risks

April 14, 2026 — Meghan Douris - Construction Executive
Labor shortages in the construction industry have become more than a scheduling headache—they are a legal and financial risk multiplier. As contractors scramble to meet deadlines with limited manpower, shortcuts in compliance, safety and subcontractor oversight become more likely. These gaps can expose companies to regulatory penalties, contractual disputes and reputational damage. Understanding how workforce constraints intersect with labor laws and contractual obligations is critical to mitigating the risks and navigating these challenges without compromising compliance or project integrity. The construction industry has faced persistent workforce challenges for years, but recent trends have intensified the problem. Factors such as an aging workforce, reduced immigration and post-pandemic recovery pressures have left contractors struggling to find skilled labor. According to Associated Builders and Contractors, the construction workforce shortage surpassed half a million workers in 2024; in the same year, Associated General Contractors reported 88% of construction companies had difficulty finding qualified workers. Reprinted courtesy of Meghan Douris, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Real Estate & Construction News Roundup (7/8/26) – Data Centers Negotiate Flexibility for Speed, Hotel Deal Activities Focus on Luxury, and DC Sues Apartment Owners

July 20, 2026 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, rail projects gain steam across the U.S., AI optimizes building operations, a modular approach speeds data center construction, and more!

Hyperscalers want their data centers online, and utilities want to provide interconnections, but both are still looking for common operating guidelines. (Herman K. Trabish, Construction Dive)
Contractors are taking advantage of multibillion-dollar train and transit contracts, even as funding challenges create hurdles for project execution. (Matthew Thibault, Construction Dive)
Although hospitality and leisure M&A deal volume was down 2.5% in the first half of 2026 compared to the prior six months, investors are concentrating on the upper end of the market, including luxury hotels, wellness resorts and gaming, or “data-rich,” platforms. (Noor Adatia, Hotel Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Real Estate & Construction News Roundup (8/19/26) – Single-Family Housing Investors Worry, Confidence in Multifamily REITs and Construction Backlog Falls

September 08, 2026 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, U.S. Chamber of Commerce creates Housing Advisory Council, a legal battle develops over new federal rules related to mortgage escrow accounts, hospitality dealmakers pursue ‘bigger, higher-conviction’ M&A, and more!

In the wake of the 21st Century ROAD to Housing Act becoming law, the U.S. Chamber of Commerce has created a Housing Advisory Council with the goal of advancing market-driven policies that help increase housing supply and promote affordability. (Julie Strupp, Multifamily Dive)
Investors in the single-family housing market are increasingly concerned about interest rates, rising insurance and home costs, and the ongoing war with Iran. (Diana Olick, CNBC)
A legal battle is brewing over new federal rules related to accounts that hold money to pay homeowners’ property taxes and insurance payments. (Sarah Agostino, CNBC)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Sixth Circuit Revives Builder’s Risk Coverage, Refusing to Let Insurer Escape on a Technicality

July 27, 2026 — Kevin V. Small & Adriana A. Perez - Hunton Insurance Recovery Blog
In 3371 Reading, LLC v. Liberty Mutual Group, the Sixth Circuit did something courts do not always do in coverage disputes: it refused to let an insurer avoid liability based on a technical policy condition that could never actually be satisfied. The decision is a straightforward reminder of two core principles. First, policies must be interpreted from the standpoint of a reasonably prudent insured. Second, hyper-technical conditions cannot be used to deny coverage where compliance is never possible. Reprinted courtesy of Kevin V. Small, Hunton Andrews Kurth LLP and Adriana A. Perez, Hunton Andrews Kurth LLP Mr. Small may be contacted at ksmall@hunton.com Ms. Perez may be contacted at pereza@hunton.com Read the full story...

How AI Turns Construction Documents Into Procurement Intelligence

May 05, 2026 — Aarni Heiskanen - AEC Business
MEP equipment accounts for up to 40% of costs on data center or hospital projects, has lead times ranging from 20 weeks to over a year, and has historically been the most underserved area in construction software. In this episode, I speak with Victor Muchiri from BuildVision about what it actually takes to make AI useful in construction procurement, not as a pilot, but in production. We dig into why you cannot simply upload a set of construction drawings to ChatGPT and trust the output. Construction documents are complex, cross-referenced, and consequential. Without deep domain context, such as manufacturer ontologies, equipment taxonomies, and engineering expertise, AI produces plausible results, not reliable ones. BuildVision’s approach is to act as a harness around AI models, wrapping them in construction-specific knowledge so the output can be trusted for real procurement decisions. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

New Report Outlines Roadmap for Construction Jobsites to Cut Carbon Emissions by 2040

April 20, 2026 — PCL Construction
Denver, Colo., April 16, 2026 (GLOBE NEWSWIRE) -- A new industry report outlines five practical steps that, when implemented together, could reduce construction jobsite emissions by up to 75% without compromising cost, schedule or performance. Grounded in real operational data from 617 construction projects across the U.S. and Canada, Growing and Greening Canadian Construction represents the most comprehensive sector-wide analysis of jobsite emissions conducted to date. The report was developed through a collaboration among leading general contractors, including PCL Construction, in partnership with the Transition Accelerator, an organization that drives projects, partnerships, and strategies to promote economic competitiveness in a carbon‑neutral world. The report focuses specifically on emissions from construction jobsite activities and reflects a shared commitment to advancing practical, scalable solutions for the industry. About PCL Construction PCL is a group of independent construction companies that operates throughout the United States, Canada, the Caribbean and Australia. As one of the largest contracting organizations in North America, PCL completes more than $9.9 billion USD in work annually, building projects that shape communities. The company’s 100% employee ownership model fuels a culture of commitment for clients in the buildings, civil infrastructure, heavy industrial and solar markets. With a strategic presence in more than 30 major centers, PCL’s leadership teams consistently drive innovation and set new benchmarks for excellence, bringing unparalleled skill to every project. Watch us build at PCL.com. About the Transition Accelerator The Transition Accelerator works with 300+ partner organizations across Canada to build out pathways to a prosperous low-carbon economy and avoid costly dead-ends along the way. We help governments and industry harness the global shift towards clean growth to secure permanent jobs, abundant energy, and strong regional economies across the country. By connecting systems-level thinking with real-world analysis, we’re enabling a more affordable, competitive, and resilient future. Read the full story...

ANDREAS PENNSYLVANIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES