Credibility Matters…Even in Delay Claims
September 29, 2026 —
David Adelstein - Florida Construction Legal UpdatesCredibility matters. Here’s another example involving a delay claim on public private partnership delivery method.
The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
Over 50 Lewis Brisbois Attorneys Recognized in 7th Edition of Best Lawyers: Ones to Watch in America
September 01, 2026 —
Lewis Brisbois56 Lewis Brisbois attorneys across 26 offices have been named to the 7th edition of “Best Lawyers: Ones to Watch in America.” Congratulations to the following attorneys on this recognition!
You can see the full list of Lewis Brisbois attorneys named to Best Lawyers' 33rd edition of The Best Lawyers in America
here.
Akron, OH
- Partner Meleah M. Skillern - Commercial Litigation
Atlanta, GA
- Partner Catherine Crawley - Personal Injury Litigation – Defendants; and Transportation Law
- Associate Davis Lackey - Insurance Law; and Personal Injury Litigation – Defendants
Read the full story...Reprinted courtesy of
Lewis Brisbois
Could Your Project-Level AI Prompt Become the Other Side’s Smoking Gun?
October 20, 2026 —
Ryan Glass - ConsensusDocsA dispute is brewing on the project. Wanting a quick assessment, the project manager opens ChatGPT, Claude, or another generative artificial intelligence (“AI”) platform. The project manager types the dispute background into the prompt, including concerns, explanations, and a frank discussion of what may have gone wrong on the contractor-side. The AI response identifies potential weaknesses in the contractor’s position, including possible failures to meet contractual obligations. Unhappy with the answer, the project manager starts a new chat, revises the prompt, and tries again. If the dispute escalates to arbitration or litigation, can the owner force the contractor to provide these prompts and the resulting responses?
Frustratingly, the answer is: it depends. Courts have reached different conclusions. For now, the safest course is to involve your counsel before using AI to evaluate a demand letter, default notice, or threatened lawsuit, or before using AI to draft dispute-related emails, claim letters, or other communications that contain project-specific facts. Otherwise, what feels like a private conversation may later become key evidence for the opposing party.
Read the full story...Reprinted courtesy of
Ryan Glass, Jones Walker LLCMr. Glass may be contacted at
rglass@joneswalker.com
Insurer Dispenses with Bad Faith Claim on Summary Judgment
June 22, 2026 —
Tred R. Eyerly - Insurance Law HawaiiThe court granted the insurer’s motion for partial summary judgment because the insured failed to present evidence that the insurer failed to conduct a reasonable investigation. PSY Burger, LLC v. State Farm General Insurance Company, 2026 U.S. Dist. LEXIS 66991(C.D. Cal. March 20, 2026).
The insured’s commercial property suffered heavy damage from tropical storm Hilary. State Farm denied coverage to repair the damage. The insured sued State Farm alleging breach of contract and bad faith due to an inadequate investigation. Apparently, the insured did not retain an expert to opine on claims handling.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Colorado’s New Mechanics’ Lien Protections: What S.B. 26-074 Means for Your Next Project
October 27, 2026 —
Maria Conversa - Snell & WilmerStarting August 12, 2026, Colorado’s mechanics’ lien statute underwent its most significant update in years. Colorado’s General Assembly enacted Senate Bill 26-074 on April 6, 2026, and the new law directly addressed a problem that has plagued contractors and subcontractors for decades. For years, a contractor and subcontractor who filed a lien for the full amount it believed was due — particularly when that amount included disputed costs, delay damages, or lost productivity — risked triggering the “excessive lien” penalty. That penalty could force the claimant to forfeit its lien rights entirely and pay the other side’s attorney fees. The new law expands the categories of costs to be claimed by good-faith lien claimants, while still protecting against truly abusive filings. General contractors, subcontractors, suppliers, owners, and lenders all need to understand these changes.
What the Bill Changed
1. Lien Value May Include Disputed Amounts
The bill amends the core lien statute to insert the phrase “whether disputed or undisputed” into the description of lienable value. Prior law referenced only “the value” of labor, services, or materials furnished. The new text confirms that a lien can attach for amounts the parties still dispute. A claimant no longer needs the owner or general contractor to agree on the amount before filing.
Read the full story...Reprinted courtesy of
Maria Conversa, Snell & WilmerMs. Conversa may be contacted at
mconversa@swlaw.com
Ball Janik LLP Strengthens Miami Construction Defect Team with Litigator Nicolas Aixala
October 26, 2026 —
Ball Janik LLPMIAMI, FL, October 22, 2026 —
Ball Janik LLP has added Nicolas Aixala to its Construction Defect Practice Group as an associate in the firm's Miami office. Aixala brings experience in construction and civil litigation, along with a perspective many litigators don't have: a view from the public side of development, gained researching land use and zoning matters for the City of Miami.
"Construction disputes in South Florida rarely stay inside the four walls of a building. Zoning, permitting, and local regulation are often part of the story," said James C. Prichard, Managing Partner of Ball Janik LLP. "Nicolas has seen that landscape from the city's side of the table, and he pairs it with solid litigation training. That combination helps us quickly size up the development and regulatory issues our clients face. We're glad to have him on our Miami team."
Before joining Ball Janik, Aixala clerked at Miami-area law firms, supporting attorneys in construction litigation and a range of civil matters through legal research, motion practice, discovery, deposition preparation, and trial preparation. He also interned with the City of Miami, assisting with legal research and opinions on land use and zoning matters, including the City of Miami Zoning Code, known as Miami 21. That work gave him a close look at how local policy shapes development, and how it affects the neighborhoods and property owners who live with the results.
"A building is one of the biggest investments a property owner will ever make, and when construction goes wrong, they need advocates who understand both the courtroom and the local landscape," said Aixala. "Ball Janik handles complex construction litigation with a practical, client-focused approach. I'm excited to bring my litigation experience and local knowledge to this team and to the property owners it serves across South Florida."
Aixala earned his J.D. from the University of Miami School of Law, where he was a member of the Yvette Ostolaza Mock Trial Team and the Cuban American Bar Association. He received his B.S. in Business Administration from the University of Central Florida, with a minor in Legal Studies and a certificate in Entrepreneurship.
About Ball Janik LLP
Ball Janik LLP is a Florida-based law firm offering construction defect, construction law, insurance recovery, and commercial litigation counsel, to its local and national clients. The firm was founded in 1982 and has expanded its capabilities, professionals, and geographic footprint. What started as a small firm focused on real property, land use, and litigation (known then as Ball Janik & Novack) has grown to a team of 70-plus attorneys and paralegals in five offices in Florida, with centuries of combined experience and capabilities. The firm has been recognized by Chambers USA, including for its construction law capabilities in Florida, U.S. News & World Report and Best Lawyers®, The Best Lawyers in America©, Super Lawyers, and Corporate International. Read more at
www.balljanik.com.
We’re Burning Tokens to Clean Up Bad PDFs
August 24, 2026 —
Aarni Heiskanen - AEC BusinessLast Thursday, researchers from Tampere and Aalto universities reported on preliminary results of two AI- and digitalization-related projects. One project demonstrated how AI can automate the Bill of Materials process; the other tried to quantify the impact of data-driven construction and AI. The conclusion was that AI-powered automation can dramatically increase productivity, but unevenly. However, the substantial benefits may come from better outcomes rather than project efficiency.
Various standards, company-specific practices, project-specific schemas, and traditions are designed for humans to comprehend. 2D drawings and text documents as PDF files, Excel sheets, and design and planning software have the information, but not the data in ideal form for automation.
Read the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
aec-business@aepartners.fi
Wilke Fleury Attorneys Recognized by 2026 Northern California Super Lawyers and Rising Stars!
July 20, 2026 —
Wilke FleuryWilke Fleury is pleased to announce that 18 of the firm’s attorneys have been selected for inclusion on the 2026 Northern California Super Lawyers and Rising Stars lists.
The annual Super Lawyers and Rising Stars selections recognize attorneys across a wide range of practice areas. This year’s honorees reflect the depth of Wilke Fleury’s litigation, business, healthcare, employment, bankruptcy, appellate, real estate, construction, and estate planning practices.
Read the full story...Reprinted courtesy of
Wilke Fleury