My Current Love-Hate Relationship with AI
June 08, 2026 —
Garret D. Murai - California Construction Law BlogIt’s early in the relationship, I know. But still, there are some things that bug me. Yet, I also know that it’s a relationship in which leaving is not an option, and even if I could, it’s not to the point where it’s so bad that I would do so. So, if you would, let me gripe a bit.
While there’s been much discussion about AI and, at least in my neck of the woods, a fair amount of discussion about how lawyers can, should, and must use AI or risk becoming discarded into the dustbin of history, much less has been written about clients’ use of AI.
Increasingly, I’ve gotten the sense that my clients are using AI. For example, I had a client ask for confirmation that if he disagreed with an administrative decision that he could file a writ of mandate, and if so, whether that deadline was 30, 60 or 90 days after the administrative decision. The answer to the first question was yes, and as to the second question, the answer was 90 days. This was from a client who, smart as he is, probably didn’t know this off the top of his head.
Read the full story...Reprinted courtesy of
Garret D. Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Humanoid Robots in Construction: The Reality Right Now
October 12, 2026 —
Aarni Heiskanen - AEC BusinessHumanoid robots are getting a lot of media attention. Videos of robots doing backflips and kung fu moves suggest that a general-purpose machine worker is just around the corner. A recent visit by the Finnish technology magazine
Tekniikka&Talous to crane manufacturer
Konecranes offers a more sober picture. I think it is a useful reality check for anyone in the AEC industry wondering what humanoids can actually do today.
What a Humanoid Can Do in a Controlled Environment
Konecranes bought a
Unitree G1 EDU humanoid in autumn 2025, likely as the first Finnish industrial company to do so. With separately purchased five-finger hands and other extras, the price came close to €100,000.
Read the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
aec-business@aepartners.fi
Nationwide Preliminary Injunction Ordering Department of Defense to Resume Review of Wind Energy Projects
September 21, 2026 —
Victor J. Roehm III, Christopher P. Colyer & Sara M. Ajeti - Snell & WilmerOn August 6, 2026, the U.S. District Court for the District of Oregon granted a preliminary injunction in Renewable Northwest v. Hegseth, Case No. 3:26-cv-01092-IM, ordering the Department of Defense (DoD) to resume processing wind energy project applications under the existing statutory and regulatory framework and staying DoD’s review freeze pending final adjudication on the merits.
Background
In 2011, Congress created the Military Aviation and Installation Assurance Siting Clearinghouse (Clearinghouse) within DoD to review wind energy projects that might affect military operations. When a wind project developer files an application with the Federal Aviation Administration (FAA), the FAA refers it to DoD to determine whether the project poses an “unacceptable risk to the national security.”
Reprinted courtesy of
Victor J. Roehm III, Snell & Wilmer,
Christopher P. Colyer, Snell & Wilmer and
Sara M. Ajeti, Snell & Wilmer
Mr. Roehm may be contacted at vroehm@swlaw.com
Mr. Colyer may be contacted at ccolyer@swlaw.com
Ms. Ajeti may be contacted at sajeti@swlaw.com
Read the full story...
The Deadline to File Suit on a Public Works Payment Payment Bond is Triggered by a Claimant’s Work on a Project Not by a Claimant’s Work Under a Contract
June 02, 2026 —
Garret D. Murai - California Construction Law BlogCalifornia law requires that prime contractors furnish a payment bond – providing for payment to lower-tiered subcontractors and suppliers – on state and local public works projects with a value in excess of $25,000. There are three conditions that must be satisfied when a claimant makes a claim against a payment bond on a public works project in California:
- First, generally, the claimant must have served a preliminary notice, unless the claimant is a first-tier subcontractor or supplier;
- The claimant must have “ceased to provide work” on the project; and
- The claimant must file suit against the payment bond no later than six (6) months after the period in which a stop payment notice must be given or, in other words, the earlier of 270 days after completion of the public works project or 210 days after a notice of completion or cessation was recorded on a public works project.
In
Tarlton & Sons, Inc. v. Great American Insurance Company, 111 Cal.App.5th 376 (2025), the 2nd District Court of Appeal examined whether a subcontractor timely filed a claim against a payment bond when a prime contractor was terminated and replaced by another prime contractor who the subcontractor continued to perform work for.
Read the full story...Reprinted courtesy of
Garret D. Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Credibility Matters…Even in Delay Claims
September 29, 2026 —
David Adelstein - Florida Construction Legal UpdatesCredibility matters. Here’s another example involving a delay claim on public private partnership delivery method.
The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
Trial-Tested Property Litigator Kimberlee Martin Joins Ball Janik LLP's Orlando Construction Defect Team
October 06, 2026 —
Ball Janik LLPORLANDO, FL, September 30, 2026 — Ball Janik LLP has added Kimberlee A. Martin to its Construction Defect Practice Group as an associate in the firm's Orlando office. For more than a decade, she has litigated matters in the fields of criminal defense, first-party property, and insurance disputes, taking cases and claims from inception through jury trial. It's the same path many of Ball Janik's clients face when construction goes wrong, and her arrival deepens the firm's trial bench in Central Florida.
"Florida property owners are dealing with complex building problems and less time to act on them. That puts a premium on attorneys who can take a case the distance," said James C. Prichard, Managing Partner of Ball Janik LLP. "Kimberlee has carried property and insurance claims from pre-suit all the way through trial, working hand in hand with experts along the way. Community associations and commercial property owners need exactly that combination, and she brings it to our team on day one."
Most recently, Kimberlee served as Litigation Director, where she oversaw homeowners' property claims in pre-suit and litigation, managed a substantial caseload, and guided associate attorneys on litigation strategy. Her civil work includes jury trials, summary judgment and dismissal motions, expert and witness depositions, mediations, and site inspections, along with close coordination with contractors, consultants, and other experts.
That skill set maps directly onto construction defect and insurance recovery litigation, where cases often turn on site evidence, expert testimony, and a credible readiness to go to trial.
"I've seen firsthand how much is at stake when a building has problems: owners' investments, residents' homes, and everyone's peace of mind," said Kimberlee. "Ball Janik is focused on exactly those clients, which made this a natural next step for my practice. I'm excited to join this team and help property owners hold the responsible parties accountable and get their buildings repaired."
Kimberlee earned her J.D., cum laude, from Florida International University College of Law and her B.A. in political science, with a minor in legal studies, from the University of Central Florida.
About Ball Janik LLP
Ball Janik LLP is a Florida-based law firm offering construction defect, construction law, insurance recovery, and commercial litigation counsel, to its local and national clients. The firm was founded in 1982 and has expanded its capabilities, professionals, and geographic footprint. What started as a small firm focused on real property, land use, and litigation (known then as Ball Janik & Novack) has grown to a team of 70-plus attorneys and paralegals in five offices in Florida, with centuries of combined experience and capabilities. The firm has been recognized by Chambers USA, including for its construction law capabilities in Florida, U.S. News & World Report and Best Lawyers®, The Best Lawyers in America©, Super Lawyers, and Corporate International. Read more at www.balljanik.com.
Snell & Wilmer’s Los Angeles Office Recognized as One of the “Best Places to Work” by the Los Angeles Business Journal
September 15, 2026 —
Snell & WilmerLOS ANGELES – Snell & Wilmer is proud to announce that its Los Angeles office has been named one of the
2026 Best Places to Work by the Los Angeles Business Journal as part of its annual Best Places to Work awards. The recognition honors outstanding employers across the Los Angeles region that are fostering strong workplace cultures and creating positive employee experiences. Selections are based on confidential employee surveys conducted by Workforce Research Group, which evaluate organizations on leadership, corporate culture, communication, employee engagement, and other key workplace factors.
“We are honored to be recognized as one of the Best Places to Work in Los Angeles,” said
Joshua Schneiderman, managing partner of the firm’s Los Angeles office. “This recognition reflects the collaborative culture we have built and the dedication of our attorneys and professional staff who contribute to making our office a great place to work. We remain committed to providing opportunities for growth, fostering meaningful connections, and supporting our team members’ continued success.”
Read the full story...Reprinted courtesy of
Snell & Wilmer
Ahlers Cressman & Sleight PLLC Recognized by Best Lawyers 2027
September 28, 2026 —
Ahlers Cressman & Sleight PLLCContinuing the trend from last year, Ahlers Cressman & Sleight PLLC is excited to announce that thirteen members of our firm have received recognition from Best Lawyers® in America for 2027.
The Best Lawyers in America® has been an annual publication since 1983 and focuses on the top legal talent across the United States and the globe. Through its rankings, Best Lawyers® provides a comprehensive guide to legal representation for individuals and businesses alike. Over time, Best Lawyers® has been recognized as one of the leading publications for attorney achievements and references.
Read the full story...Reprinted courtesy of
Ahlers Cressman & Sleight PLLC
