CORBIN VIRGINIA CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Delay Matters: Florida’s Fourth DCA Reverses Hurricane Irma Dismissal

June 08, 2026 — Andrea DeField, Machaella Reisman & Cary D. Steklof - Hunton Insurance Recovery Blog
The mantra “delay, deny, defend” is frequently referenced in discussions of insurance claims handling, though insurers will invariably disavow these tactics. While it would be facially improper for an insurer to delay a coverage decision to gain a tactical advantage, empirical examples nonetheless exist. This very dynamic was addressed by Florida’s Fourth District Court of Appeals when it handed policyholders a win in Hypoluxo Mariner’s Cay Condo. Assoc’n, Inc. v. Underwriters at Lloyd’s London, No. 4D2024‑2250 (Fla. 4th DCA Apr. 1, 2026), reversing a trial court order dismissing a condominium association’s Hurricane Irma coverage lawsuit against its property insurer. Delay to Run the Statute of Limitations Following Hurricane Irma, a condominium association suffered roof and exterior envelope damage, reported an insurance claim, and submitted a sworn proof of loss to its property insurer in compliance with Florida Statute § 627.70132 (2020). The statute establishes a timeframe within which a policyholder must submit a claim for hurricane damage. Reprinted courtesy of Andrea DeField, Hunton Andrews Kurth LLP, Machaella Reisman, Hunton Andrews Kurth LLP and Cary D. Steklof, Hunton Andrews Kurth LLP Ms. DeField may be contacted at adefield@hunton.com Ms. Reisman may be contacted at reismanm@hunton.com Mr. Steklof may be contacted at csteklof@hunton.com Read the full story...

---

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Voluntary Dismissal of an Indemnity Claim Does Not Make the Subcontractor a “Prevailing Party,” Washington Court of Appeals Holds

September 21, 2026 — Margarita Kutsin - Ahlers Cressman & Sleight PLLC
In King County v. Walsh Construction Company II, LLC, No. 86503-0-I (Wash. Ct. App. Aug. 4, 2025), an unpublished decision from Division I of the Washington Court of Appeals, the Court affirmed the denial of a subcontractor’s request for prevailing-party attorney fees under an indemnity clause after the general contractor voluntarily dismissed its indemnity claims. Because the indemnity claim was no longer live and no determination of fault had occurred, the Court held that the trial court did not err in denying the request. ACS represented Walsh, the general contractor, in securing the denial of the fee request at the trial court that the Court of Appeals affirmed. A Pass-Through Indemnity Claim That Ended Before Fault Was Decided The dispute arose out of a public works contract under which King County hired Walsh Construction Company II, LLC (“Walsh”) to construct and install a conveyance pipeline. After the pipeline broke, King County sued Walsh for breach of contract and warranty, expressly identifying both Walsh and its subcontractor, Mears Group Inc., (“Mears”) as responsible. Walsh tendered defense and indemnity to Mears under the subcontract. Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight PLLC
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

---

Insured’s Failure to Determine Depreciation When Presenting Claim for Replacement Cost Value

August 16, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Third Circuit affirmed the district court’s granting of summary judgment to the insurer when the insured submitted replacement cost value of the loss but did not include a determination of depreciation. Kimmel v. Massachusetts Bay Ins. Co., 2026 U.S. App. LEXIS 16569 (3d Cir. June 9, 2026). A lightning strike downed a tree on the insured’s property, causing extensive damage to the home. The insured had a homeowner’s policy with Massachusetts Bay Insurance Company (MBIC). MBIC denied the claim, determining that much of the claimed damage already existed and that several policy exclusions otherwise barred coverage. The insured filed suit for breach of contract and bad faith. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

White and Williams LLP is Proud to Host the 20th Anniversary Virginia Barton Wallace Award and Reception

May 05, 2026 — White and Williams LLP
White and Williams LLP is proud to host the 20th Anniversary Virginia Barton Wallace (VBW) Award and Reception, which will celebrate this year’s honoree, The Rendell Center for Civics & Civic Engagement. This award was created to celebrate the remarkable career of Virginia “Ginny” Barton Wallace, the first woman to be elected to partnership not only at White and Williams but also at any law firm in Philadelphia. The VBW Award is presented to a woman or organization that embodies the same qualities that Ginny possessed: leadership, drive, exemplary work ethic, overall excellence in her field, or an ability to inspire other women to succeed. Read the full story...
Reprinted courtesy of White and Williams LLP

---

Celebrating Freedom: The Overlooked Freedom to Contract in Commercial Insurance

July 20, 2026 — Michael S. Levine & Andrea DeField - Hunton Insurance Recovery Blog
Happy 4th and 250 years of freedom . . . to contract! Many policyholders assume insurance policies are “standard” and must be accepted as-is. That assumption is often wrong—and dangerously limiting. Unlike many consumer insurance markets, the commercial insurance realm preserves a robust “freedom to contract,” allowing sophisticated policyholders to negotiate terms, exclusions, definitions, and limits before a policy is even issued. Particularly in recent years, high-profile disputes over cyber coverage, business interruption, and war/cyber exclusions have shown not just what happens when coverage is denied, but what could have been done up front to avoid those fights. This post highlights the power policyholders still hold in the negotiation process and illustrates, with concrete examples from recent media-covered disputes, how that freedom can be strategically used. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth LLP and Andrea DeField, Hunton Andrews Kurth LLP Mr. Levine may be contacted at mlevine@hunton.com Ms. DeField may be contacted at adefield@hunton.com Read the full story...

---

Lost in Translation: AEC Tech’s Missing Role

May 12, 2026 — Aarni Heiskanen - AEC Business
I once visited a construction site where the contractor’s headquarters had commissioned a tech company to build an on-site quality-inspection application. The developer had admitted to the site engineer that they had never set foot on a construction site before. The engineer showed me what he was actually using: his own phone camera and an Excel sheet. The new app did not map to how work actually happened on site. This is not an isolated story. The vendor builds something technically coherent but operationally disconnected. The client, somewhere up the chain, had fallen in love with the idea of the solution before anyone had built an honest business case for it. The result is a tool that gets demonstrated at a board meeting but isn’t used in the field. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Appeals Court Upholds Skanska, Granite Win in ‘I-4 Ultimate’ JV Dispute

June 15, 2026 — Bryan Gottlieb - Engineering News-Record
A federal appeals court has upheld a lower court’s decision requiring The Lane Construction Corp. to pay roughly $79 million in damages, plus interest, to joint venture partners Skanska USA Civil Southeast and Granite Construction for work on Florida’s I-4 Ultimate highway megaproject in Orlando, which was completed in 2022. Read the full story...
Reprinted courtesy of Bryan Gottlieb, Engineering News-Record
Mr. Gottlieb may be contacted at gottliebb@enr.com

---