Bay Center Washington Construction Expert Witness Directory

Function Over Form: Eighth Circuit Narrows Application of Cosmetic Damage Exclusion

October 12, 2026 — Ali Jamwal - SDV Fenchurch
Introduction In a significant decision for policyholders, the United States Court of Appeals for the Eighth Circuit adopted a narrow interpretation of an exclusion for cosmetic roof damage caused by wind or hail.[1] The court held that for a cosmetic damage exclusion to apply, an insurer must prove that the roof’s ability to function as a barrier to the elements is not impaired as compared to its functionality prior to the loss or damage. Background In April 2022, a hailstorm struck the insured school buildings causing indentations in the buildings’ metal roofs. The hail did not puncture the roofs’ metal, and no leaks were reported. The insurer denied the claim based on the policy’s cosmetic damage exclusion, which precluded coverage for “cosmetic damage to roof surfacing caused by wind and/or hail.” Cosmetic damage was defined as “superficial damage that altered the appearance of the roof surfacing, but such damage does not prevent the roof from continuing to function as a barrier to entrance of the elements to the same extent as it did before.” Read the full story...
Reprinted courtesy of Ali Jamwal, SDV Fenchurch
Mr. Jamwal may be contacted at ali.jamwal@sdvfenchurch.us

New York Team Secures Dismissal of Premises Liability Action Against Client

May 26, 2026 — Lewis Brisbois
New York Associate Nicole Koch and Partner Jennine Gerrard recently secured a complete dismissal of a plaintiff’s claims for injuries following a fall in front of a client’s business at an outdoor mall. The plaintiff alleged that she was walking on the sidewalk outside of the client's hair care supply store in the Bronx in May 2024 when she tripped and fell on a broken/defective portion of the sidewalk. As a result of the accident, the plaintiff suffered injuries to her spine, hip, wrist, and both knees. She proceeded to file suit in New York County Supreme Court against Lewis Brisbois’ client and the landlord for the property. Read the full story...
Reprinted courtesy of Lewis Brisbois

Differing Site Conditions Claim Requires a Misrepresentation

May 14, 2026 — David Adelstein - Florida Construction Legal Updates
If you are entertaining a differing site conditions claim, consider this Third District Court of Appeals case from the mid-90s. In Hendry Corp. v. Metropolitan Dade County, 648 So.2d 140 (Fla. 3d DCA 1995), a contractor was hired by Dade County to demolish the old Rickenbacker Causeway in Miami. The original 1941 plans of the causeway were made available to contractors. The lowest bidding contractor that was awarded the project based its bid “on its conclusion that the pilings supporting the old bridge were made of concrete.” Hendry, supra at 141. The contractor based this conclusion on the original plans, its visual observation, and experience. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

$356 Million Judgement Against Developer for Defective Construction of DC Condominium

August 16, 2026 — Nicholas D. Cowie - Cowie Law Group
On July 31, 2026, the Superior Court of the District of Columbia entered a $356,085,513.00 judgment against developers JBG Smith for defective construction and renovation of the Wardman Tower Residential Condominium in Washington, D.C. The case is Wardman Tower Residential Condominium Unit Owners Association v. JBG Smith Properties, et al., No. 2020 CA 004807 B (D.C. Super. Ct.). In a 148-page Trial Order, the D.C. Superior Court awarded $118,695,171.00 in damages in favor of the condominium association and against the condominium developers, including JBG Smith. The Court trebled those damages pursuant to the District of Columbia Consumer Protection Procedures Act (“CPPA”) to reach an ultimate judgment of $356,085,513.00. See Cowie Law Group: DC Condominium Construction Defects: Recovering Attorney’s Fees, Litigation Expenses & Treble Damages Under the Consumer Protection Procedures Act. Cowie Law Group, P.C. filed the lawsuit on behalf of the Association in 2020. The firm represented the Association throughout years of pretrial discovery and ultimately served as trial counsel with Williams & Connolly LLP during a lengthy bench trial before the Honorable Yvonne Williams. The Cowie Law Group team included attorneys, George A. Bealefeld, III, Albert G. McCarraher, Stanford L. Kimmel, III and Nicholas D. Cowie. Read the full story...
Reprinted courtesy of Nicholas D. Cowie, Cowie Law Group
Mr. Cowie may be contacted at ndc@cowielawgroup.com

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Did You Know: Unique Legal Considerations for Animal Care Facilities

August 24, 2026 — Hannah Skidmore - Construction Executive
Animal care facilities are highly specialized environments that require expertise far beyond traditional commercial or even standard medical construction. Whether designing and building animal shelters, doggy daycares, veterinary clinics or full-service animal hospitals, these facilities operate under conditions that introduce unique challenges related to sanitation, durability, animal behavior and operational workflows. Because of these complexities, projects that fail to account for animal care requirements adequately often encounter costly issues—many of which result in litigation. Below are real-world examples drawn from expert witness work, followed by proactive best practices construction professionals should apply to future animal care projects. Reprinted courtesy of Hannah Skidmore, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Nordics Are Europe’s Next Data Center Hub

October 05, 2026 — Aarni Heiskanen - AEC Business
On September 9, 2026, Google announced its largest single investment in Europe. The company commits at least €13 billion to Finnish data centers and energy infrastructure in 2027 and 2028, expanding the existing Hamina campus and adding three new sites in Kajaani, Muhos, and Vaala. For the construction sector, this is great news: thousands of hectares, dozens of buildings, and a construction program that will extend well beyond the two-year investment window. Four Sites, One Regional Cluster Google is not a newcomer in Finland. Back in 2009, it converted a former paper mill in Hamina into a seawater-cooled data center. It has invested around €4.5 billion there over 15 years, and the site’s waste heat already feeds Hamina’s district heating network. The new program shifts the center of gravity north, to the border of North Ostrobothnia and Kainuu. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Chambers USA Recognizes GRSM as 2026 Industry Leader

June 29, 2026 — Gordon Rees Scully Mansukhani
Gordon Rees Scully Mansukhani has once again been recognized by Chambers USA, a prestigious directory of the country’s top law firms. In addition to the firm’s practice recognitions, eight partners, David Capell, Nancy Erfle, Matthew Foy, Ashlee Grant, Craig Heryford, Andrew Port, Todd Regan, and Angela Richie, were recognized among the nation’s top lawyers in their respective fields. Chambers USA recognized the firm in the following eight categories: USA – Nationwide – Insurance: Dispute Resolution: Insurer, Band 4 The firm is widely sought after by national insurance sector clients facing a wide array of coverage disputes as well as bad faith claims. The firm has additional capabilities in class actions and appellate litigation. Its broad base of experience includes professional liability, construction, and bankruptcy-related issues. This is the third year the firm has received this recognition. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

BAY CENTER WASHINGTON CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES