PULLMAN WASHINGTON CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Construction Liens: Liening for Amounts Not Yet Technically Due Does Not Mean Lien Is Fraudulent

August 11, 2026 — David Adelstein - Florida Construction Legal Updates
A 2024 bankruptcy ruling, In re Edgewater Construction Group, Inc., 657 B.R. 668 (S.D.Fla. 2024), touched upon an interesting issue when it comes to construction liens. Is a construction lien fraudulent simply because the lien includes amounts not yet due? Not necessarily. In this bankruptcy dispute, the subcontractor debtor (that filed for bankruptcy) recorded two construction liens on projects. The general contractor argued in the bankruptcy court that the subcontractor debtor’s liens were fraudulent. As to the first lien, the general contractor argued that the lien was fraudulent because it included amounts that the debtor knew the general contractor had already paid to the debtor’s subcontractors/suppliers. The bankruptcy court disagreed: “The Court finds that, although the Debtor had been told that [the general contractor] had paid these subcontractors, in light of the ongoing dispute between Debtor and [the general contractor], it was reasonable for the Debtor to demand proof. Debtor’s subsequent filing of a partial satisfaction of lien once the Debtor received the requested proof of payment from [the general contractor] counters any claim of willful exaggeration.” In re Edgewater Construction Group, supra, at 672-673. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Contractor Dispute Resolution Framework and Prevention

July 06, 2026 — Construction Executive
WHAT DEFINES A CONTRACTOR DISPUTE RESOLUTION FRAMEWORK A contractor dispute resolution framework is a structured system of contractual terms, governance processes and escalation pathways designed to prevent, manage and resolve conflicts between contracting parties with minimal disruption to cost, schedule and performance. The framework operates as both a preventive control and a corrective mechanism. Preventive elements establish clarity in scope, expectations and accountability before work begins. Corrective elements define how disagreements are identified, documented, escalated and resolved once they arise. Reprinted courtesy of Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Shane Singh Named One of Los Angeles Business Journal's 'Top 100 Lawyers of Los Angeles' for 2026

April 27, 2026 — Lewis Brisbois
Sacramento Partner Shane Singh has been named one of the Los Angeles Business Journal's "Top 100 Lawyers of Los Angeles" for 2026. The LABJ’s annual list honors Los Angeles' top lawyers for their achievements within the city's business community. Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Newmeyer Dillion Ranked in Chambers Spotlight California 2026 Guide

May 26, 2026 — Newmeyer Dillion
NEWPORT BEACH, Calif. – May 14, 2026 - Prominent business and real estate law firm Newmeyer Dillion has been ranked in Chambers Spotlight California 2026 guide and recognized as a leading firm in Litigation: General Commercial for Orange County. Newmeyer Dillion was selected based on an independent and in-depth market analysis, coupled with an assessment of the firm’s experience, expertise and caliber of talent where the firm stood out for its exceptional work and is recognized in Litigation: General Commercial. Managing Partner Paul Tetzloff expressed the firm's gratitude: “It is an honor for our firm to be recognized by Chambers and Partners in their Spotlight California 2026 guide. This acknowledgment reflects our commitment to providing high quality legal services tailored to the unique needs of our clients.” Read the full story...
Reprinted courtesy of Newmeyer Dillion

---

What Construction Attorneys Do and When Contractors Need Them

August 11, 2026 — Construction Executive
Direct Answer A construction attorney advises contractors on contracts, payment rights, mechanic's liens, payment bond claims, change orders, delay claims, OSHA matters, defect claims, terminations and dispute resolution. The work covers far more than lawsuits—much of its value comes before a dispute ever becomes formal. Construction attorneys help contractors protect payment rights, manage project risk, resolve disputes and avoid contract terms that can turn a profitable job into a financial loss. Their work covers more than lawsuits. A construction attorney may review a contract before bid day, help preserve lien rights, respond to a defective work claim, prepare for mediation or defend a contractor after a safety citation. For contractors, legal counsel is often most valuable before a dispute becomes formal. A missed notice deadline, vague scope clause, unsigned change order or broad indemnity provision can create problems long before a claim is filed. Construction attorneys help identify those risks while there is still time to negotiate, document the issue or preserve leverage. Reprinted courtesy of Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Navigating Timelines and Technology: Patent Strategies for Space and Earth

June 01, 2026 — Kate Nuehring Su & Vanessa Wang - Engineering News-Record
More than half a century after the Apollo 11 landing fulfilled President John F. Kennedy’s bold vision, the global race back to the Moon is no longer theoretical. With renewed attention on NASA’s Artemis program and a surge of commercial investment in space infrastructure, lunar exploration is again shaping technology priorities here on Earth. Reprinted courtesy of Kate Nuehring Su, Engineering News-Record and Vanessa Wang, Engineering News-Record Read the full story...
ENR may be contacted at enr@enr.com

---

Four Kahana Feld Attorneys Selected to 2027 Southern California Super Lawyers® and Rising Stars Lists

August 16, 2026 — Kahana Feld
IRVINE, CA – Aug. 3, 2026 – Kahana Feld is pleased to announce that partners Jason Feld, Amir Kahana, and Sharon Oh-Kubisch were selected to the 2027 Southern California Super Lawyers list, and attorney Hannah Ellenhorn Bloom was selected to the 2027 Southern California Super Lawyers Rising Stars list. Jason Feld was recognized in the area of Construction Litigation. He is a founding partner of Kahana Feld and focuses his practice on the defense of homebuilders, contractors, developers, and real estate professionals primarily in construction defect, general liability, insurance defense, construction accident, and real estate matters. He also represents government entities handling construction, premises liability, general liability, and environmental claims. He serves as panel counsel for many prominent insurance carriers, as well as personal counsel to several national and regional homebuilders, developers, and general contractors. Read the full story...
Reprinted courtesy of Kahana Feld

---