Anaheim California Construction Expert Witness Directory

Enforceability of Contract Provisions Extending Liquidated Damages Beyond Substantial Completion

April 15, 2024 — Stu Richeson - The Dispute Resolver
This post takes a look at the enforceability of contract provisions providing for liquidated delay damages after substantial completion. Typically, the assessment of liquidated delay damages ends at substantial completion of a project. However, various standard form contracts, including some of the ConsensusDocs and EJCDC contracts, contain elections allowing for the parties to agree on the use of liquidated damages for failing to achieve substantial completion, final completion, or project milestones. The standard language in the AIA A201 leaves it up to the parties to define the circumstances under which liquidated damages will be awarded. Courts are split on the enforceability of provisions that seek to assess liquidated damages beyond substantial completions. Courts in some jurisdictions will not impose liquidated damages after the date of substantial completion on the ground that liquidated damages would otherwise become a penalty if assessed after the owner has put the project to its intended use. Perini Corp. v. Greate Bay Hotel & Casino, Inc., 129 N.J. 479, 610 A.2d 364 (1992). When the terms are clear, other jurisdictions will enforce contract terms providing for liquidated damages until final completion, even if the owner has taken beneficial use of the facility. Carrothers Const. Co. v. City of S. Hutchinson, 288 Kan. 743, 207 P.3d 231 (2009). Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

A Brief Primer on Perfecting Your Mechanics Lien When the Property Owner Files Bankruptcy

January 22, 2024 — William L. Porter - Porter Law Group
Overview of the Mechanics Lien Law This is a brief description of steps to be taken when the Owner of property on which you have recorded a mechanics lien files bankruptcy. The California mechanics lien is a powerful tool for contractors, subcontractors and materials suppliers to secure payment of unpaid construction debts. A contractor, subcontractor or materials supplier is allowed to record a mechanics lien on real property, based on the value added to the property by the claimant during the construction process. The recorded mechanics lien provides the claimant with legal right to force the sale of the improved real property and thereby obtain the funds necessary to pay the delinquent debt. Under the usual procedure, the first step is the recording of the mechanics lien with County Recorder’s office in the County where the property is located. A lawsuit to foreclose on the lien must then be filed in the County Superior Court of that County, within ninety (90) days after the mechanics lien is recorded. The goal of the lawsuit is to obtain a judgment for foreclosure on the mechanics lien in order to force a sale of the property. The net proceeds of the sale will be used to pay the unpaid construction debt secured by the recorded mechanics lien, assuming sale proceeds exceed the amount of senior liens and encumbrances. Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

Appraisal Goes Forward Even Though Insurer Has Yet to Determine Coverage on Additional Claims

December 11, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The trial court's order granting the insured's motion to stay litigation and compel an appraisal was affirmed even though the insurer had not determined coverage on the insured's additional claims.Heritage Prop. & Cas. Ins. Co. v. Wellington Place HOA, 2023 Fla. App. LEXIS 6405 (Fla. Ct. App. Sept. 13, 2023). The insured homeowner's association reported roof damage to its insurer, Heritage, after Hurrican Irma struck. Heritage agreed the damage was covered, but issued no payment because the amount of loss was less than the deductible. The insured hired its own adjuster. The insured requested an extension of the policy's two year time limit to complete repairs because the claim was still in dispute and the insurer had not yet paid sufficient funds to allow necessary repairs. Heritage sent a revised estimate and asked the insured to send its adjuster's estimate in order to address any disputes. The insured submitted its adjuster's estimate of more than $6 million, including, for the first time, the cost to replace all the windows and sliding glass doors. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Payne & Fears LLP Recognized by Best Lawyers in 2024 “Best Law Firms” Rankings

November 27, 2023 — Payne & Fears LLP
Payne & Fears LLP has been recognized by Best Lawyers 2024 “Best Law Firms” list. Firms included in the 2024 edition of Best Lawyers “Best Law Firms” are recognized for professional excellence with consistently impressive ratings from clients and peers. Payne & Fears LLP has been ranked in the following practice areas:

Metropolitan Tier 1
- Orange County
  - Commercial Litigation
  - Employment Law – Management
  - Insurance Law
  - Labor Law – Management
  - Litigation – Labor & Employment
  - Litigation – Real Estate

Metropolitan Tier 2
- Las Vegas
  - Commercial Litigation

Metropolitan Tier 3
- Orange County
  - Litigation – Intellectual Property

Read the full story...

The New York Lien Law - Top Ten Things You Ought to Know

December 23, 2023 — Ralph E. Arpajian - White and Williams LLP
Over the course of my career, I have had the privilege of working with and representing numerous construction lenders (and borrowers/developers) in the financing of some of the largest commercial projects in the United States. A number of these projects have been in New York, where one encounters the New York Lien Law (the “Lien Law”). Many of my clients, particularly those lenders, borrowers, and their counsel, located outside of New York, are often perplexed by my advice regarding the Lien Law and the loan structuring requirements which result. In the hope that it would be helpful (especially for non-New York counsel), I have compiled a “top ten” list outlining, in my view, the most critical (and most perplexing) aspects of structuring New York construction loans under the Lien Law. Read the full story...
Reprinted courtesy of Ralph E. Arpajian, White and Williams LLP
Mr. Arpajian may be contacted at arpajianr@whiteandwilliams.com

Navigating Threshold Arbitration Issues in Construction Contracts

April 29, 2024 — Daniel D. McMillan and TJ Auner - The Dispute Resolver
Including an arbitration clause in your construction contract may not mean that your dispute will be confined to arbitration. Instead, parties often find themselves in court litigating threshold issues related to the existence and/or enforceability of an arbitration clause. Common issues include whether the underlying contract containing the arbitration clause is valid, whether the dispute falls within the scope of the clause, whether the parties complied with contractual prerequisites to arbitration, whether issues related to arbitrability are decided by the court or arbitrator, and whether one of the parties has waived their right to arbitrate. This blog post highlights two recent construction cases addressing threshold issues that a party seeking to enforce—or oppose enforcing—an arbitration clause might face. Seifert v. United Built Homes, LLC: Delegating Issues of Arbitrability to the Arbitrator In Seifert, an owner sued a homebuilder in Texas federal court for breach of contract and sought damages and declaratory relief. No. 3:22-CV-1360-E, 2023 WL 4826206 (N.D. Tex. July 27, 2023). The builder moved to compel arbitration. The owner opposed and argued that: (1) there was no agreement to arbitrate because the underlying contract was null and void, and (2) its claim for declaratory relief fell outside the scope of the arbitration clause. The court did not address the merits of either argument. Instead, it determined that these were issues for the arbitrator to decide. Reprinted courtesy of Daniel D. McMillan, Jones Day and TJ Auner, Jones Day Mr. McMillan may be contacted at ddmcmillan@jonesday.com Mr. Auner may be contacted at tauner@jonesday.com Read the full story...

Appraisal Panel Can Determine Causation of Loss under Ohio Law

February 19, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court granted the insured's motion to compel an appraisal that would include a determination of causation of the loss. Eagle Highland Owners Association v. State Farm Fire and Casualty Co., 2023 U.S. Dist. LEXIS 220937 (S.D. Ohio Dec. 12, 2023). Plaintiff argued its property suffered wind and hail damage from a storm on June 18, 2021. A claim was submitted to State Farm. State Farm's investigation determined the loss to be $0.00. Plaintiff's investigator determined the loss to be $586,647.08 in repair costs. State Farm opposed appraisal because, in its view, the damage arose from a loss in 2019, not from the June 18, 2021 storm. Plaintiff submitted a loss claim in 2019 for damage that State Farm alleged was exactly the same as the damage alleged in the loss claim for the June 18, 2021 storm. Therefore, State Farm did not view the matter as a dispute over an amount of loss, but rather over whether a loss even occurred on June 18, 2021. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Veolia Agrees to $25M Settlement in Flint Water Crisis Case

February 19, 2024 — James Leggate - Engineering News-Record
Engineering firm Veolia North America agreed to a $25-million settlement to resolve a federal class action case related to its work for the city of Flint, Mich., during the city’s lead-in-water crisis, the company and attorneys for the plaintiffs announced Feb. 1. Veolia is the second engineering firm that worked for the city to settle with city residents, and the deal came ahead of a class-action trial scheduled to start later this month. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story...

ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES