No Damages for Delay May Not Be Enforceable in Virginia
January 08, 2024 —
Christopher G. Hill - Construction Law MusingsAnyone who reads Construction Law Musings with any regularity (thank you by the way) knows that the contract is king in most instances here in Virginia. Any commercial construction subcontractor in Virginia is likely also very familiar with so-called “no damages for delay” clauses in construction contracts. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the general contractor, is an extension of time to complete the work. However, in 2015 the Virginia General Assembly passed a change in the law that precluded the diminishment of any right to claims for demonstrated additional costs prior to payment. This left open the question as to which types of “diminishment” would be barred by the statute.
The recent case out of the Eastern District of Virginia federal court, Strata Solar LLC v. Fall Line Construction LLC, added a bit of clarity.
Read the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Congratulations to BWB&O’s Newport Beach Team for Prevailing on a Highly Contested Motion to Quash!
January 08, 2024 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPCongratulations to Newport Partners Tyler Offenhauser and Jonathan Cothran, and Associate Anisha Kohli, who recently prevailed on behalf of BWB&O’s client before the Orange County Superior Court on a highly contested Motion to Quash Service based on Plaintiff’s failure to timely file and serve a DOE Amendment, naming our client.
BWB&O’s client was the owner of a building where Plaintiff, a licensed electrician, was electrocuted while performing an upgrade to the building’s electrical infrastructure. Plaintiff’s original lawsuit named only the building’s tenant, who was also represented by BWB&O. BWB&O was successful earlier this year on a Motion for Summary Judgment under the Privette Doctrine and won judgment on behalf of the client/tenant. While that MSJ was pending, Plaintiff surreptitiously added the building’s owner to the suit with a DOE Amendment, after several months earlier learning the owner and then tenant were entities operated by the same individual. However, Plaintiff never informed counsel or any other party of the filing. Moreover, after the MSJ was granted, Plaintiff then waited several more months to serve the building’s owner.
Read the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Build, Baby, Build. But Not Like This, Britain.
March 04, 2024 —
Matthew Brooker - BloombergThe UK needs to do a lot more building. A lack of access to physical and digital connections is holding back the economy, the government says. Besides tackling the housing crisis, the country has to construct more roads, railways, wind farms and reservoirs to open up opportunity and drive productivity. The only problem is that Britain is notoriously inept at delivering infrastructure projects on time and within budget.
The advantage of doing things badly is that at least you get to learn from your mistakes — in theory. Updates this month have offered some illuminating insights into two of the biggest civil-engineering undertakings in the country: High-Speed Rail 2, better known as HS2, and Hinkley Point C, which will be Britain’s first new nuclear power station since 1995. Here are five lessons that can be drawn from the issues encountered by two projects with a combined bill that’s likely to exceed £100 billion ($127 billion):
Don't take budgets too seriously — especially at the start. Fixing an initial budget that was too low may have done much to feed later perceptions that HS2’s costs were spiraling out of control. The original estimate for the expanded train network was set too early and based on “very immature data,” Jon Thompson, appointed executive chair of High Speed 2 Ltd. in February last year, told the House of Commons transport committee. Numbers get more accurate and reliable as work progresses and the quality of information improves. What were viewed as cost blowouts partly reflected this process. The effect was unfortunate, undermining political support for HS2 and providing cover for cutbacks that have reduced the network to a single line between London and Birmingham that fails to fulfill most of its original purpose. To avoid this problem: Stick to a range rather than a single figure, and make sure people understand the uncertainties inherent in early-stage estimates.
Read the full story...Reprinted courtesy of
Matthew Brooker, Bloomberg
Waiving Consequential Damages—What Could Go Wrong?
March 19, 2024 —
Curtis W. Martin & Kellie M. Ros - Peckar & Abramson, P.C.You are inexcusably late with construction of a football stadium, a casino, or similar project that generates large income for the owner. The indirect damages, often referred to as consequential damages, that flow from the delay can be astronomical to the point of breaking your company if it must pay them. As a result, many construction contracts, at every tier, contain a provision that waives consequential damages. By this waiver, a party seeks to limit its risk for these damages.
Over the years, courts have interpreted these provisions in a widely variable and inconsistent manner. The courts typically start with the specific language of the waiver to discern the parties’ intent. Thus, the language of the provision itself is critical. But construction professionals should not overlook other provisions in the contract that may have an impact on a court’s analysis of the parties’ intent. As one of my colleagues likes to say, “the large print giveth and the small print taketh away.”
Reprinted courtesy of
Curtis W. Martin, Peckar & Abramson, P.C. and
Kellie M. Ros, Peckar & Abramson, P.C.
Mr. Martin may be contacted at cmartin@pecklaw.com
Ms. Ros may be contacted at kros@pecklaw.com
Read the full story...
Breach of Contract Exclusion Bars Coverage for Construction Defect Claim
March 19, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe court determined the policy's breach of contract exclusion precluded coverage for a claim against the general contractor insured for construction defects. Mt. Hawley Ins. Co. v. McAtamncy, 2024 U.S. Dist. LEXIS 497 (N. D. Cal. Jan. 2, 2024).
McAtamney, a general contractor dong business as Kilrea Construction, was hired by Jeffrey Horowitz for a home-renovation project. After completion of the project, Horowitz discovered defects in the work. He filed a complaint alleging that Kilrea breached obligations to construct and complete the work in an expeditious and workmanlike manner, free from any faults and defects. He brought claims for breach of contract, breach of implied warranty, negligence, neglignet supervision, and declaratory relief.
Kilrea's insurer, Mt. Hawley, agreed to defend, but reserved the right to later deny coverage for any uncovered claims. The breach of contract exclusion provided there was no duty to defend a claim for property damage arising from breach of an express or implied contract or warranty.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Does “Faulty Workmanship” Constitute An Occurrence Under Your CGL Policy?
January 08, 2024 —
David Adelstein - Florida Construction Legal UpdatesThere is nothing more scintillating than an insurance coverage dispute, right? Well, some folks would agree with this sentiment. Others would spit out their morning coffee in disagreement. Regardless of where you fall in the spectrum, they are always important because maintaining insurance is a NECESSARY part of business, particularly in the construction industry. The ideal is to have insurance that covers risks you are assuming in the performance of your work.
Sometimes, insurance coverage disputes provide valuable insight, even in disputes outside of Florida. Recently, the Western District of Kentucky in Westfield Insurance Co. v. Kentuckiana Commercial Concrete, LLC, 2023 WL 8650791 (W.D.KY 2023), involved such a dispute. While different than how Florida would treat the same issue, it’s still noteworthy because it sheds light into how other jurisdictions determine whether “faulty workmanship” constitutes an “occurrence” under a commercial general liability (CGL) policy.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Competitive Bidding Statute: When it Applies and When it Does Not
April 15, 2024 —
Mason Fletcher - Ahlers Cressman & Sleight PLLCThe University of Washington (UW), a public university, aimed to secure a real estate developer for a new building on its campus. The proposal involved an 80-year ground lease (the “Lease”), and developers submitted bids. The selected developer would demolish an existing building, construct a new one, own it during the Lease at its own cost, and UW would lease back a portion, with ownership reverting to UW at the Lease’s end. Alexandria Real Equities, Inc. (ARE) was a finalist but ultimately was not selected, and the Lease was awarded to Wexford Science and Technology, LLC (Wexford). As a result, ARE filed suit against UW asserting three claims: 1) UW lacked authority to execute the Lease, 2) UW didn’t follow required competitive bidding procedures, and 3) UW’s developer selection process was arbitrary and capricious. None of these claims were successful and ARE appealed.
Division II of the Washington Court of Appeals affirmed in Alexandria Real Estate Equities Inc. v. Univ. of Wash., __ Wn. App. __, 539 P.3d 54 (2023), a published decision. The Court concluded, based on the facts in that case, that because construction was not publicly funded, UW did not have to follow competitive bidding requirements that were laid out in a statute relevant to state universities. Still, the Court applied the “bright-line cutoff point” that prohibits disappointed bidders from challenging an award once a contract has been executed. See Dick Enterprises, Inc. v. Metro. King County, 83 Wn. App. 566, 572, 922 P.2d 184 (1996).
Read the full story...Reprinted courtesy of
Mason Fletcher, Ahlers Cressman & Sleight PLLCMr. Fletcher may be contacted at
mason.fletcher@acslawyers.com
Illinois Supreme Court Holds that Constructions Defects May Constitute “Property Damage” Caused By An “Occurrence” Under Standard CGL Policy, Overruling Prior Appellate Court Precedent
January 08, 2024 —
Jason Taylor - Traub Lieberman Insurance Law BlogOn November 30, 2023, the Illinois Supreme Court issued an opinion that overturned precedent in Illinois regarding whether faulty workmanship that only caused damage to the insured’s own work constituted “property damage” caused by an “occurrence” under Illinois law. In Acuity v. M/I Homes of Chicago, LLC, 2023 IL 129087, the Illinois Supreme Court considered whether Acuity, a mutual insurance company, had a duty to defend its additional insured, M/I Homes of Chicago, LLC (M/I Homes), under a subcontractor’s commercial general liability (CGL) policy in connection with an underlying lawsuit brought by a townhome owners’ association for breach of contract and breach of an implied warranty of habitability. The Cook County Circuit Court granted summary judgment in favor of Acuity finding no duty to defend because the underlying complaint did not allege “property damage” caused by an “occurrence” under the initial grant of coverage of the insurance policy. The appellate court reversed and remanded, finding that Acuity owed M/I Homes a duty to defend. The Illinois Supreme Court affirmed, in part, holding construction defects to the general contractor’s own work may constitute “property damage” caused by an “occurrence” under the standard CGL Policy. This is significant as it overrules prior Illinois precedent finding that repair or replacement of the insured’s defective work does not satisfy the initial grant of coverage of a CGL Policy.
By way of background, the underlying litigation stems from alleged construction defects in a residential townhome development in the village of Hanover Park, Illinois. The townhome owners’ association, through its board of directors (the Association) subsequently filed an action on behalf of the townhome owners for breach of contract and breach of the implied warranty of habitability against M/I Homes as the general contractor and successor developer/seller of the townhomes. The Association alleged that M/I Homes’ subcontractors caused construction defects by using defective materials, conducting faulty workmanship, and failing to comply with applicable building codes. As a result, “[t]he [d]efects caused physical injury to the [t]ownhomes (i.e. altered the exterior’s appearance, shape, color or other material dimension) after construction of the [t]ownhome[ ] was completed from repeated exposure to substantially the same general conditions.” The defects included “leakage and/or uncontrolled water and/or moisture in locations in the buildings where it was not intended or expected.” The Association alleged that the “[d]efects have caused substantial damage to the [t]ownhomes and damage to other property.”
Read the full story...Reprinted courtesy of
Jason Taylor, Traub LiebermanMr. Taylor may be contacted at
jtaylor@tlsslaw.com