Anaheim California Construction Expert Witness Directory

Graham & Who May Trigger The Need To Protest

December 23, 2023 — Hugo Fraga - Ahlers Cressman & Sleight PLLC
On May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner. This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project. Read the full story...
Reprinted courtesy of Hugo Fraga, Ahlers Cressman & Sleight PLLC
Mr. Fraga may be contacted at hugo.fraga@acslawyers.com

Washington’s Court of Appeals Protects Contracting Parties’ Rights to Define the Terms of their Indemnity Agreements

March 19, 2024 — Margarita Kutsin - Ahlers Cressman & Sleight PLLC
It has long been the law in Washington that contracting parties are free to draft contractual indemnity agreements to allocate risk arising from performance of the work, and Courts will generally enforce those agreements as written. This well-settled principle was recently reaffirmed in King County v. CPM Development Corp., dba ICON Materials[1] a decision from Division I of the Washington Court of Appeals, wherein one party to an indemnity agreement attempted to evade its contractual obligations by arguing that certain common law indemnity principles supersede the written terms. This appeal followed a multi-week jury trial from which the client and Ahlers Cressman and Sleight legal team, including Lindsay Watkins, Klien Hilliard, and Christina Granquist, obtained a seven-figure judgment in the client’s favor, including an award of all attorneys’ fees and costs. ICON was the general contractor on a Vashon Island Highway Pavement project for King County. Part of the work on the project involved hauling away and disposing of ground milled asphalt (the “millings”) at King County-approved sites. ICON and D&R Excavating Inc., (“D&R”) executed a subcontract for D&R to perform that work. The subcontract incorporated the contract between ICON and King County, including the obligation to stockpile millings only at approved sites. D&R, however, did not obtain the requisite approvals from King County, and placed the millings at various sites on the Island, including locations that King County explicitly rejected. Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight PLLC
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Missouri Protects Subrogation Rights

April 15, 2024 — Lian Skaf - The Subrogation Strategist
The point at which an insurance carrier possesses the equitable right of subrogation is an issue on which the states have differed. Some allow carriers to pursue rights of subrogation immediately upon payment and some have taken stricter approaches. Missouri falls into the latter group. By not allowing the carrier the right to file suit against third-party tortfeasors until the insured provides its carrier with an assignment of all its rights, Missouri’s approach has opened the door for challenges to subrogation rights. In Megown v. Auto Club Fam. Ins. Co., 2024 Mo. App. LEXIS 82, the plaintiff-insureds Michael and Jane Megown (the Megowns) suffered a house fire on February 8, 2016. Their insurance carrier, Auto Club Family Insurance Company (Auto Club) reimbursed the Megowns for their property damage in the amount of $722,433.56. Subsequently, the Megowns sued Auto Club for breach of contract and later amended their complaint to add claims against Tyberius Enterprises, LLC d/b/a Crag Electric (Craig Electric), the third-party tortfeasor, for direct negligence, alleging both property damage and personal injuries. Auto Club intervened in the Megowns’ claim against Craig Electric to protect its interest as subrogee for its property damage payment to the Megowns. Craig Electric settled prior to trial, paying $1,000,000.00 to both the Megowns and Auto Club, to be allocated at a later date. After a bench trial that apportioned the settlement with $722,433.56 paid to Auto Club and $277,566.44 paid to Megowns – and a jury trial awarding no further damages – the Megowns appealed. Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

A Guide to California’s Changes to Civil Discovery Rules

April 29, 2024 — Lewis Brisbois Newsroom
San Diego, Calif. (April 10, 2024) - California legislators have changed the rules of discovery in civil cases through the passage of amendments to Code of Civil Procedure sections 2016.090 and 2023.050, effective January 1, 2024. Section 2016.090 creates a new set of rules for civil litigators in cases filed on or after January 1, 2024, which permits any party to the litigation to demand initial disclosures be provided within 60-days. Such a demand can be made any time after a party has filed a responsive pleading, including a demurrer or motion to strike. Notably, this rule requires production of all information relevant to any causes of action that are pled at the time of the demand, meaning the parties may be required to disclose information related to claims that are being challenged on demurrer or a motion to strike, such as claims for punitive damages. This statute is only implicated when one of the parties to the action makes a demand and may be modified by stipulation of the parties. Read the full story...
Reprinted courtesy of Lewis Brisbois

Judicial Economy Disfavors Enforcement of Mandatory Forum Selection Clause

December 16, 2023 — David Adelstein - Florida Construction Legal Updates
Mandatory forum (venue) selection provisions are generally construed in favor of enforceability. Parties agreed to the forum for disputes so why not enforce them, right? A recent federal district court case out of the Eastern District of Louisiana exemplifies an exception grounded in judicial economy which disfavors the enforceability of mandatory forum selection provisions. Keep in mind that this judicial economy exception is fairly limited but the fact pattern below demonstrates why enforcing the mandatory forum selection provision was disfavored due to judicial economy. In U.S. f/u/b/o Exposed Roof Design, LLC v. Tandem Roofing, 2023 WL 7688584 (E.D.La. 2023), a sub-subcontractor filed a Miller Act payment bond lawsuit against the prime contractor and the prime contractor’s Miller Act payment bond sureties. The sub-subcontractor also sued the subcontractor that hired it. However, the sub-subcontractor’s subcontract with the subcontractor included a mandatory forum selection provision in a different form. The subcontractor moved to sever and transfer the sub-subcontractor’s claims against it to the forum agreed upon in the subcontract. The trial court denied the severance and the transfer. Below are the reasons. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

The New York Lien Law - Top Ten Things You Ought to Know

December 23, 2023 — Ralph E. Arpajian - White and Williams LLP
Over the course of my career, I have had the privilege of working with and representing numerous construction lenders (and borrowers/developers) in the financing of some of the largest commercial projects in the United States. A number of these projects have been in New York, where one encounters the New York Lien Law (the “Lien Law”). Many of my clients, particularly those lenders, borrowers, and their counsel, located outside of New York, are often perplexed by my advice regarding the Lien Law and the loan structuring requirements which result. In the hope that it would be helpful (especially for non-New York counsel), I have compiled a “top ten” list outlining, in my view, the most critical (and most perplexing) aspects of structuring New York construction loans under the Lien Law. Read the full story...
Reprinted courtesy of Ralph E. Arpajian, White and Williams LLP
Mr. Arpajian may be contacted at arpajianr@whiteandwilliams.com

How I Prevailed on a Remote Jury Trial

March 04, 2024 — Samuel Yu - Kahana Feld
Are you crazy? That is what I asked my client when he asked me to conduct a jury trial remotely. At the time, I did not even know if it was feasible. While I figured that most courtrooms had remote capabilities, I was not sure whether anyone was crazy enough to do a jury trial remotely and whether a courtroom would accommodate it. Would I be able to truly connect with the jurors? Would the jurors hold it against me that I am appearing remotely while they have to be there in person? I told my client that this was a terrible idea but that I would at least see if it was an option. At the Final Status Conference, the Court confirmed that it could accommodate a remote appearance for both the party and the party’s counsel and gave its permission to do so. It was also clear that I would be the only attorney exercising this option, and the judge remarked that this would be a first for him. Appearing remotely while other attorneys appear in person is not something I would normally consider. However, this case presented a unique set of circumstances. Read the full story...
Reprinted courtesy of Samuel Yu, Kahana Feld
Ms. Yu may be contacted at syu@kahanafeld.com

The Black Woman Architect Who Hopes to Change the Face of Design in America

January 16, 2024 — Kriston Capps - Bloomberg
In the US, only 2% of licensed architects are Black. Less than a single percent are Black women. Architects tend to be older, White and men, as reflected by the leadership of both firms and professional groups. So when the American Institute of Architects inaugurated its 100th president, Kimberly Dowdell — the first Black woman to lead the association, and at 40 the youngest architect to ever hold the post — it suggested an optimistic change of course. A principal and director of strategic relationships for the global design firm HOK, Dowdell comes to her new position from a leadership background. She has served as the president of the National Organization of Minority Architects and sits on the board of the Chicago Central Area Committee and Chicago Architecture Biennial, among other groups. She is the winner of both the AIA’s Young Architects Award and the Women in Architecture award from Architectural Record. Dowdell spoke to Bloomberg CityLab about her goals as AIA president, the challenges facing the field and why every city should hire its own chief architect. Read the full story...
Reprinted courtesy of Kriston Capps, Bloomberg

ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES