Colorado’s New Mechanic’s Lien Law: Bigger Claims, Stronger Protections, and New Risks for Owners and Contractors
October 12, 2026 —
David McLain - Colorado Construction Litigation BlogOn April 6, 2026, the same day that the Colorado Supreme Court issued its decision in Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners, Governor Jared Polis signed Senate Bill 26-074 into law. The legislation, which took effect on August 12, 2026, clarifies the amounts that may be included in mechanic’s liens and public construction payment claims, as well as the circumstances under which those claims may be considered excessive.
While the timing of the Supreme Court’s decision and the Governor’s approval of SB 26-074 is noteworthy, the legislation has implications extending beyond the public works claims addressed in Wadsworth. Most significantly, it expressly addresses disputed and unliquidated amounts, including delay and disruption costs, in mechanic’s liens filed against private construction projects.
Read the full story...Reprinted courtesy of
David McLain, Higgins, Hopkins, McLain & Roswell, LLCMr. McLain may be contacted at
mclain@hhmrlaw.com
Beyond the Storm: How Non-Hurricane Catastrophes Expose Florida’s Construction Defect Blind Spot
August 11, 2026 —
Franchesco “Frank” Soto & Amanda L. Gonzalez - Ball JanikOn June 8, 2026, a magnitude 6.1 earthquake struck the Gulf near the coast of Cuba, the largest instrumentally recorded earthquake in the Gulf since seismic monitoring began in 1950. Buildings swayed, offices were evacuated, and many residents along the east coast of Florida, from Miami-Dade to Jacksonville, felt the ground shake. Although no tsunami followed and reported structural damage was limited, this event exposed a blind spot that Florida property owners, developers, and their counsel cannot afford to ignore: catastrophic stress on Florida buildings does not always come in the form of a named storm.
Florida property owners have grown accustomed to preparing for wind, storm surge, floods, and torrential rain. Far less attention is paid to earthquakes, sinkholes, tornadoes, hail, and non-tropical flooding, each of which can place unexpected stress on buildings not designed with those forces top of mind and can trigger deficiencies in buildings that were not otherwise known, expose design failures, and create an urgency for both insurance claims and subsequent litigation.
Non-Hurricane Triggers of Latent Defects
Seismic activity is the clearest example. Florida’s building code accounts for wind loads, not seismic forces, meaning even a moderate earthquake can reveal weaknesses in curtain wall systems, structural connections, or foundations that were already marginal. Sinkholes, driven by Florida’s karst limestone geology, remain a persistent threat, particularly in Central Florida, where subsurface voids can undermine foundations without warning. Non-tropical flooding, like the record rainfall that flooded South Florida in June 2024, can intrude through building envelopes and waterproofing systems that were never stress-tested for such volumes of water. Tornadoes and hail, while more localized, can cause roofing and envelope failures that mimic, mask, or trigger latent construction defects.
The Litigation and Coverage Disputes That Follow
When one of these events strikes a building already carrying undisclosed or unresolved construction defects, the resulting disputes become considerably more complex. Property owners and associations must move quickly to document existing conditions and distinguish damage caused by the event from pre-existing defective construction, the same causation issue that arises in the hurricane context under Chapter 558, but often without the benefit of established precedent or adjuster experience with these less common events.
Insurance coverage disputes frequently follow close behind. Carriers may dispute whether an earthquake, flood, or other peril is covered at all, particularly where policies contain earthquake or flood exclusions requiring separate endorsements, or anti-concurrent causation language that can bar coverage entirely when a covered peril combines with an uncovered one, such as pre-existing defective construction, to cause a loss. Sinkhole claims carry their own statutory framework under Florida law, requiring specific testing protocols and reporting before a claim is compensable. Developers and contractors, in turn, may find themselves defending Chapter 558 claims while simultaneously litigating with their own carriers over defense and indemnity obligations.
Practical Risk Mitigation Strategies
Property owners, associations, and developers can take several concrete steps to reduce their exposure. First, maintain thorough documentation, including engineering reports, maintenance logs, and photographs, well before any event occurs. This documentation is often the deciding factor in causation disputes. Second, engage structural engineers and consultants immediately following any seismic event, unusual flooding, or storm damage, regardless of whether a hurricane is involved. Prompt inspection preserves evidence and can help prevent inadvertent waiver of construction defect claims. Third, review insurance policies regularly with counsel or a broker to confirm earthquake, flood, and sinkhole coverage matches the property’s actual risk profile, rather than assuming a standard property policy responds to every peril. Fourth, avoid rushing to remediate before conditions are documented and/or before consulting counsel. Well-intentioned repairs can inadvertently compromise evidence needed to prove a defect claim.
The June earthquake was a reminder that Florida’s catastrophic risk profile extends beyond hurricane season. Property owners, associations, and developers who build readiness plans around all forms of catastrophic stress, not just named storms, will be far better positioned when the next unexpected event occurs.
Franchesco “Frank” Soto is a partner in
Ball Janik’s Construction Defect Practice Group in Miami. He may be reached at fsoto@balljanik.com.
Amanda L. Gonzalez is a litigation attorney in
Ball Janik’s Construction Defect Practice Group in Miami. She may be reached at agonzalez@balljanik.com.
Chambers USA Recognizes Hunton’s Insurance Coverage Practice in 2026 Guide
June 29, 2026 —
Hunton Insurance Recovery BlogHunton is pleased to announce that its insurance coverage practice was recognized nationally for Insurance: Dispute Resolution – Policyholder in the recently released 2026 Chambers USA guide. The team also received state rankings in Florida (Insurance: Dispute Resolution), Georgia (Insurance), the District of Columbia (Insurance: Policyholder), and Massachusetts (Insurance).
In addition to the insurance team’s group recognition across multiple states, the 2026 guide included individual rankings for
Lorelie “Lorie” S. Masters (USA Nationwide and District of Columbia),
Latosha M. Ellis (District of Columbia),
Michael S. Levine (District of Columbia),
Koorosh “KT” Talieh (District of Columbia),
Walter J. Andrews (Florida),
Andrea DeField (Florida),
Cary D. Steklof (Florida),
Lawrence J. Bracken II (Georgia), and
Geoffrey B. Fehling (Massachusetts).
Read the full story...Reprinted courtesy of
Hunton Andrews Kurth LLP
White and Williams LLP Ranked in the Chambers USA 2026 Guide
June 15, 2026 —
White and Williams LLPWhite and Williams LLP is proud to celebrate the Chambers USA 2026 Guide which has ranked several of the Firm's attorneys and practice groups, underscoring the Firm's overall commitment to providing client service excellence.
The Chambers USA 2026 Guide recognized attorneys Tim Davis, Managing Partner, and Nancy Frantz, Chair of the Real Estate Group, for Real Estate: Finance in the state of Pennsylvania. Randy Maniloff, Partner, Patricia Santelle, Chair Emeritus/Former Managing Partner, and Robert Walsh, Partner were ranked for Insurance in Pennsylvania, and Thomas Pinney, Partner, was ranked in Pennsylvania for Bankruptcy/Restructuring. In the state of Maryland, Partners David Gilliss and Eric Korphage were recognized for their work in Construction.
Read the full story...Reprinted courtesy of
White and Williams LLP
Wadsworth v. Regional Rail Partners — Verified Statements of Claim Under the Colorado Public Works Act
August 25, 2026 —
Olivia Barden - Colorado Construction Litigation BlogEditor’s Note: Wadsworth Revisited
In August 2024, following the Colorado Court of Appeals’ decision in Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners, we published
Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims.
At the time, the decision warranted a significant warning to contractors and subcontractors performing public work in Colorado. The Court of Appeals concluded that Wadsworth’s verified statement of claim improperly included unliquidated delay damages and that, because the claim was excessive, Wadsworth forfeited its right to recover the amounts included in the claim. We cautioned contractors to carefully scrutinize verified statements of claim and to avoid including unliquidated damages or amounts that were not yet due and payable.
The Colorado Supreme Court has now reversed that decision.
Read the full story...Reprinted courtesy of
Olivia Barden, Higgins, Hopkins, McLain & Roswell, LLC
Congratulations to Reno Partner Karen Baytosh for Securing a Complete Dismissal via a Motion for Summary Judgment
July 13, 2026 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPBWB&O is proud to announce that Reno Partner Karen Baytosh received a significant victory on behalf of the firm’s Developer Client in a high-exposure personal injury matter.
Plaintiff, a teenager, was struck by an intoxicated driver while walking her dog at night, sustaining catastrophic injuries requiring 24-hour critical care for the remainder of her life. Plaintiff’s Guardian brought suit against the drunk driver and her husband, the City, and BWB&O’s Developer Clients, alleging that the City and Developers failed to improve street lighting and install a sidewalk that would have prevented the accident.
Read the full story...Reprinted courtesy of
Bremer Whyte Brown & O'Meara LLP
Chambers USA Recognizes GRSM as 2026 Industry Leader
June 29, 2026 —
Gordon Rees Scully MansukhaniGordon Rees Scully Mansukhani has once again been recognized by Chambers USA, a prestigious directory of the country’s top law firms. In addition to the firm’s practice recognitions, eight partners, David Capell, Nancy Erfle, Matthew Foy, Ashlee Grant, Craig Heryford, Andrew Port, Todd Regan, and Angela Richie, were recognized among the nation’s top lawyers in their respective fields.
Chambers USA recognized the firm in the following eight categories:
USA – Nationwide – Insurance: Dispute Resolution: Insurer, Band 4
The firm is widely sought after by national insurance sector clients facing a wide array of coverage disputes as well as bad faith claims. The firm has additional capabilities in class actions and appellate litigation. Its broad base of experience includes professional liability, construction, and bankruptcy-related issues. This is the third year the firm has received this recognition.
Read the full story...Reprinted courtesy of
Gordon Rees Scully Mansukhani
Jurisdiction Over Foreign Manufacturers in Construction Litigation
May 14, 2026 —
Timothy J. Repass & Miki J. Saito - Wood Smith Henning BermanA recent decision from the Washington Court of Appeals provides important guidance on personal jurisdiction over foreign product manufacturers in construction and infrastructure litigation. In King County v. Aquatherm GmbH, No. 85572-7-I (Wash.Ct. App.Div.I)(unpublished), the court addressed whether a German manufacturer could be sued in Washington for alleged defects in piping used in major public infrastructure projects. The ruling offers a detailed, fact-driven roadmap for how Washington courts evaluate jurisdiction over foreign manufacturers operating through layered distribution networks. It also reflects a broader trend toward focusing on real-world commercial conduct rather than formal corporate structure.
Background of the Case
King County sued after widespread failures in polypropylene piping installed at the King County Correctional Facility. The pipe, manufactured by Aquatherm GmbH in Germany, was marketed, distributed, and installed through a network of U.S.-based entities. Following a six-week trial, the jury returned a verdict exceeding $18 million on claims under the Washington Product Liability Act and Consumer Protection Act. Aquatherm challenged, among other things, the trial court's exercise of personal jurisdiction.
Reprinted courtesy of
Timothy J. Repass, Wood Smith Henning Berman and
Miki J. Saito, Wood Smith Henning Berman
Mr. Repass may be contacted at trepass@wshblaw.com
Ms. Saito may be contacted at msaito@wshblaw.com
Read the full story...
