ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Weather Delay Claim - Owner Delay Pushes Contractor into Worse Seasonal Adverse Weather

November 04, 2025 — David Adelstein - Florida Construction Legal Updates
In government contracting, a contractor is entitled to a time extension for “unusually severe weather.” However, this time extension is typically not compensable (meaning you get time, but not additional compensation). However, “a contractor may bring a claim for compensable delay when government delay pushes a contractor’s performance into a period of worse seasonal adverse-but not unusually severe-weather.” Appeals of - Thalle Construction Company, ASBCA No. 63685, 2025 WL 2496328, n.10 (ASBCA 2025) (citation omitted). In a recent appeal with the Armed Services Board of Contract Appeals, a contractor pursued a weather delay claim. The contractor sought 39 days of adverse weather between the adjusted contract completion date and the actual substantial completion date claiming that the government pushed the contractor’s last 262 days of performance into worse seasonal adverse weather. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

ZEC 2.0: New York’s Zero Emissions Credit Program Gets an Extension and a Reboot

February 10, 2026 — Stephen J. Humes & Jason Drogin Atwood - Gravel2Gavel Construction & Real Estate Law Blog
In a landmark move that could shape New York’s energy landscape for decades, state officials have taken steps to both preserve its existing nuclear power facilities and significantly expand its advanced nuclear capacity. These actions are part of a broader strategy to maintain grid reliability and meet both escalating energy demand and the state’s ambitious greenhouse gas reduction and zero carbon goals. Renewing the Zero Emissions Credit Program On January 22, 2026, the New York Public Services Commission (PSC) unanimously voted to extend and reboot the Zero Emissions Credit program (now called ZEC 2.0) to ensure that New York’s four upstate nuclear reactors maintain operations through 2049. The program, which began in 2016, is designed to provide revenue subsidies for legacy nuclear facilities that have been facing financial difficulties in New York’s competitive wholesale power markets. State officials have stated that the benefits of ensuring the continued operations of these reactors far outweigh the costs due to the lack of zero-emissions alternatives and the importance of ensuring grid reliability in the face of escalating energy demand from large loads like data centers. Reprinted courtesy of Stephen J. Humes, Pillsbury and Jason Drogin Atwood, Pillsbury Mr. Humes may be contacted at stephen.humes@pillsburylaw.com Mr. Atwood may be contacted at jason.atwood@pillsburylaw.com Read the full story...

---

Seventh Circuit Finds “Additional Insured” Requirements Met Where Non-Party Subcontractor Was Proximate Cause of Underlying Injuries

February 23, 2026 — Jason Taylor - Traub Lieberman Insurance Law Blog
In Atlanta Gas Light Company et al v. Navigators Ins. Co., Nos. 24-2888 & 24-2889 (7th Cir. Jan. 22, 2026), the Seventh Circuit Court of Appeals assessed whether an upstream contractor was an “additional insured” under an umbrella policy issued to its subcontractor. Atlanta Gas and Southern Company Gas (“AGL”) hired United States Infrastructure Corporation (“USIC”) to locate and mark gas lines that AGL owned throughout Georgia. In 2018, USIC failed to mark a gas line in Homerville, Georgia, and a boring company struck it, leading to an explosion that severely injured three women. The victims settled their claims with USIC but did not come to terms with AGL. AGL eventually did settle with the victims, but only after they sued AGL in Georgia state court (the “Underlying Suits”). AGL’s service agreement with USIC required USIC to obtain primary and excess liability insurance coverage that included AGL as an additional insured. Because USIC’s settlement with the victims exhausted its primary policy, AGL tendered the defense and indemnification of the Underlying Suits to USIC’s excess insurer, Navigators. Navigators denied the request on the ground that AGL was not an “additional insured” under the policy. Read the full story...
Reprinted courtesy of Jason Taylor, Traub Lieberman
Mr. Taylor may be contacted at jtaylor@tlsslaw.com

---

Snell & Wilmer Receives Multiple National and Regional Top Tier Rankings in 2026 “Best Law Firms® Rankings” by Best Lawyers®

December 08, 2025 — Snell & Wilmer
PHOENIX – Snell & Wilmer is proud to announce it has once again been recognized by Best Law Firms®, earning 34 national and 199 regional rankings across 74 categories by Best Lawyers® in their annual Best Law Firms rankings. The firm received national Tier 1 rankings for its Bankruptcy and Creditor Debtor Rights / Insolvency and Reorganization Law, Commercial Litigation, Communications Law, Construction Law, Corporate Law, Litigation – Construction, Litigation – Labor and Employment, Litigation – Real Estate, Real Estate Law, and Securities Regulation categories. The firm also earned national rankings in 24 other categories, and 15 of its offices earned regional rankings. The 2026 Best Law Firms rankings are based on the highest number of participating firms and the highest number of client ballots on record. The rankings are determined through a rigorous evaluation process that includes the collection of client and lawyer evaluations, peer review from leading attorneys in their field, and review of additional information supporting a firm’s accomplishments. The following is the complete list of Snell & Wilmer practices ranked in the 2026 Best Law Firms: National Rankings Banking and Finance Law Bankruptcy and Creditor Debtor Rights / Insolvency and Reorganization Law Commercial Litigation Communications Law Construction Law Corporate Law Employment Law – Management Energy Law Environmental Law Financial Services Regulation Law Health Care Law Labor Law – Management Litigation – Banking and Finance Litigation – Bankruptcy Litigation – Construction Litigation – Environmental Litigation – Intellectual Property Litigation – Labor and Employment Litigation – Real Estate Litigation – Regulatory Enforcement (SEC, Telecom, Energy) Litigation – Securities Mass Tort Litigation / Class Actions – Defendants Mergers and Acquisitions Law Mining Law Native American Law Natural Resources Law Patent Law Real Estate Law Securities / Capital Markets Law Securities Regulation Tax Law Trademark Law Trusts and Estates Venture Capital Law Read the full story...
Reprinted courtesy of Snell & Wilmer

---

New California Law Requires Real Estate Agents and Brokers to Disclose AI Alterations in Listings

January 21, 2026 — Brian Slome - Lewis Brisbois
San Diego, Calif. (December 19, 2025) - Artificial intelligence and digital marketing have become ubiquitous in real estate advertising. The widespread use of AI creates risk for consumers who don’t know whether images shown online or on the multiple listing services are real. A new California law that goes into effect in January 2026 tries to draw a clear line: innovation is welcome but deception is not. The state’s new law requires licensed real estate brokers and salespersons to disclose when images used in advertisement and promotional materials have been digitally altered and to provide access to the original, unaltered images. The law is intended to enhance transparency in real estate advertising and to reduce the risk of consumer deception arising from image editing, virtual staging, or other digital modifications. Who Is Covered The law applies to real estate agents, brokers, developers, and marketing staff involved in property advertising. It encompasses advertisements including those in print and online. Read the full story...
Reprinted courtesy of Brian Slome, Lewis Brisbois
Mr. Slome may be contacted at Brian.Slome@lewisbrisbois.com

---

Brian Newberry Accepted into ABOTA

November 18, 2025 — Lewis Brisbois Newsroom
Providence, RI (October 13, 2025) - Lewis Brisbois is pleased to announce that Providence Partner Brian C. Newberry was recently accepted as a new member of the Rhode Island Chapter of the American Board of Trial Advocates (ABOTA) during the organization’s National Board Meeting in Austin, Texas on October 4, 2025. In discussing his acceptance into the organization, Mr. Newberry noted, “It’s an honor to be accepted into ABOTA. Jury trials lie at the heart of the legal system and while our first priority as lawyers is to resolve disputes as economically and efficiently as possible for our clients, part of that pursuit depends on always being ready to present a case to a jury and it is critically important for both our clients and opposing counsel to know we stand at the top of the profession in that regard.” Providence Managing Partner Lauren Motola-Davis stated, “ABOTA sets one of the profession’s highest bars for trial excellence and civility. Brian Newberry not only meets that standard - he exemplifies it. We’re thrilled for him and for ABOTA’s Rhode Island Chapter, and we know he’ll continue to strengthen Lewis Brisbois’ National Trial Practice.” Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Texas Case Exposes Cracks in the Government Contractor Immunity Shield

November 09, 2025 — Elaine Silver - Engineering News-Record
It started with a horrific crash. Pedro Alfonso Castaneda, the mainstay of a Texas family of five, had finished shopping at a plumbing supply store on an August afternoon in 2019, when he pulled up in his Toyota Tacoma pickup at an intersection adjacent to a busy highway overpass construction project in Pinehurst, Texas. Read the full story...
Reprinted courtesy of Elaine Silver, Engineering News-Record
ENR may be contacted at enr@enr.com

---

Massachusetts Nuclear Verdict Leads To $90M Bad Faith Award

February 10, 2026 — Eric B. Hermanson & Timothy J. Langan - White and Williams
Insurers in Massachusetts have long struggled with the demands of MGL ch. G.L.c 176D, § 3(9)(f), which requires “prompt, fair and equitable settlements of claims in which liability has become reasonably clear.” Last month a Superior Court ruling illustrated the potentially draconian consequences of a violation: finding an insurer liable for more than $90 million in bad faith damages, in a case that might have settled under $3 million with proper handling. The claimant, John Rooney, was a mason who fell off a scaffold at a construction site. He sued the general contractor. The general contractor, in turn, sought coverage as an additional insured under a series of Liberty Mutual policies issued to Rooney’s employer – the masonry company – with combined aggregate limits of $19.5 million. Reprinted courtesy of Eric B. Hermanson, White and Williams and Timothy J. Langan, White and Williams Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Langan may be contacted at langant@whiteandwilliams.com Read the full story...

---