Anaheim California Construction Expert Witness Directory

We Won’t Permit That Excuse!

June 23, 2026 — Curt Martin & Richard Eiszner - ConsensusDocs
A Texas appellate court recently ruled that a building permit wasn’t a condition precedent for a construction project. That caught our attention. Can you build a commercial project without a permit? But as we read the case, we see the court’s reasoning. And it reminds us of an important legal principle that should inform our contract drafting and negotiation. The case was a civil suit brought by the project owner against its tenant improvement contractor for work on a medical spa. The owner claimed that the contractor didn’t perform the work properly and didn’t finish construction. The contractor argued that delays and problems were caused by the owner, alleging numerous failures, including the owner’s failure to secure a building permit. Reprinted courtesy of Curt Martin, Peckar & Abramson, P.C. and Richard Eiszner, Peckar & Abramson, P.C. Mr. Martin may be contacted at cmartin@pecklaw.com Mr. Eiszner may be contacted at reiszner@pecklaw.com Read the full story...

Endorsement is Void Where Compliance is Impossible

September 21, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Sixth Circuit found that the insured’s loss of property due to fire was covered despite noncompliance with an endorsement requiring encompassing the property. 3371 Reading, LLC v. Liberty Mut Group, Inc., et al., 2026 U.S. App. LEXIS 19156 (6th Cir. June 29, 2026). The insured, 3371 Reading, owned a building undergoing renovation. After the structure burned down, 3371 Reading made a claim under its policy with Ohio Casualty Insurance Company. Ohio Casualty relied on an endorsement requiring fencing round the jobsite. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Structural Concerns Force Emergency Closure of Maryland Office Building

August 16, 2026 — Jim Parsons - Engineering News-Record
A 10-story Baltimore-area office building was evacuated after an underground parking structure was compromised during construction work. Read the full story...
Reprinted courtesy of Jim Parsons, Engineering News-Record
ENR may be contacted at enr@enr.com

The Best Lawyers in America® - Ball Janik Attorneys Earn Multiple Recognitions

September 01, 2026 — Ball Janik LLP
Orlando, FL, August 20, 2026 – Ball Janik LLP is pleased to announce that 24 of its attorneys have been recognized in the 2027 editions of The Best Lawyers in America® and Best Lawyers: Ones to Watch® in America. The 33rd Best Lawyers edition recognitions are based on peer review and highlight attorneys across a range of practice areas. This recognition underscores the broad experience Ball Janik's attorneys bring to the firm's construction defect practice. "We're proud to be recognized by Best Lawyers again this year," said James C. Prichard, Managing Partner of Ball Janik LLP. "These honors reflect the expertise and depth of our team, our continued growth across Florida, and our commitment to providing strong counsel to clients in complex construction, insurance recovery, and litigation matters." Ball Janik attorneys recognized in the 2027 edition of The Best Lawyers in America® include: Keegan A. Berry — Construction Law Brian T. Crevasse — Construction Law; Litigation - Construction Todd Demetriades — Litigation - Construction Joseph R. Fitos — Construction Law; Litigation - Construction Megan A. Picataggio — Construction Law Jon E. Lemole — Construction Law; Litigation - Construction Salvatore G. Scro — Construction Law Nicholas B. Vargo — Construction Law; Litigation - Construction Kelly M. Corcoran — Construction Law Gabriel Z. Coelho — Construction Law Evan J. Small — Construction Law; Litigation - Construction Franchesco Soto — Construction Law; Litigation - Construction Phillip E. Joseph — Litigation - Construction; Real Estate Law James C. Prichard — Construction Law Ball Janik attorneys recognized in the 2027 edition of Best Lawyers: Ones to Watch® in America include: Nicholas Passantino — Litigation - Construction Amanda L. Gonzalez — Construction Law; Litigation - Construction Morgan N. Lester — Litigation - Construction Chris S. Tribbey — Construction Law Kyle Bugden — Construction Law; Litigation - Construction Brian Tannenbaum — Construction Law Kayla Mosquera — Insurance Law Natasha L. Biela — Commercial Litigation Elijah C. Waring, Jr. — Product Liability Litigation - Defendants Greg K. Demers — Construction Law About Ball Janik LLP Ball Janik LLP is a Florida-based law firm offering construction defect, construction law, insurance recovery, and commercial litigation counsel, to its local and national clients. The firm was founded in 1982 and has expanded its capabilities, professionals, and geographic footprint. What started as a small firm focused on real property, land use, and litigation (known then as Ball Janik & Novack) has grown to a team of 70-plus attorneys and paralegals in five offices in Florida, with centuries of combined experience and capabilities. The firm has been recognized by Chambers USA, including for its construction law capabilities in Florida, U.S. News & World Report and Best Lawyers®, The Best Lawyers in America©, Super Lawyers, and Corporate International. Read more at www.balljanik.com.

2026 Top Business Risks for Construction and Engineering Companies

May 26, 2026 — Darren Tasker - Construction Executive
The 2026 Allianz Risk Barometer revealed some surprising findings for construction and engineering businesses. Now in its fifteenth year, this annual business risk ranking by corporate insurer Allianz Commercial incorporates the views of 3,338 global risk management professionals on the main perils on their radar for the year. Survey respondents included construction and engineering risk experts who identified the threats keeping them up at night. Here is how they ranked the top industry risks for 2026: Natural Catastrophes Natural catastrophe risk retains the top spot, with 38% of construction and engineering respondents citing this risk as their leading concern for 2026. From the insurance perspective, economic and insured losses remained high, albeit lower than the 10-year average. The evolving nature of natural catastrophes continues to pose significant challenges to businesses and the (re)insurance industry. Insured losses from natural catastrophes are set to reach $107 billion for 2025, according to Swiss Re—the sixth year in a row they have exceeded $100 billion, while economic losses are well in excess of $200 billion. Reprinted courtesy of Darren Tasker, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Your AEC Firm Has a Memory Problem. Here Is How to Fix It

June 01, 2026 — Aarni Heiskanen - AEC Business
AEC companies trying to operationalize AI often find they lack the data foundation on which to build. There may be an abundance of data hidden in documents, but you can’t reliably use it for AI. The lack of data quality was a key topic discussed at the AI in AEC 2026 conference. During the event, I met many experts working to solve this problem, including Pavlina Nikolova, Egnyte‘s EMEA AEC Practice Lead. The chat and her presentation highlighted the challenges and ways to overcome them. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

How Engineers Will Determine Why NYC's Pfizer HQ Conversion Buckled

July 13, 2026 — Bryan Gottlieb - Engineering News-Record
Construction crews have stabilized the former Pfizer headquarters redevelopment in Midtown Manhattan after two load-bearing structural columns buckled on the 21st floor July 7. The focus has now shifted from emergency response to determining what caused the office-to-residential conversion to suffer a major structural failure. Read the full story...
Reprinted courtesy of Bryan Gottlieb, Engineering News-Record
Mr. Gottlieb may be contacted at gottliebb@enr.com

Bad Faith Claim Survives Summary Judgment

June 08, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the insurer’s motion for partial summary judgment on the insured’s bad faith claim, but granted the motion on the insured’s claim for punitive damages. Serbian Orthodox Church v. Brotherhood Mut. Ins. Co., 2026 U.S. Dist. LEXIS 58234 (S.D. Cal. March 19, 2026). On February 1, 2023, the Church filed a claim for water damage with Brotherhood Mutual Insurance Company (BMIC). The claim was based on rain and wind that caused extensive water intrusion into the Sanctuary, damaging its plaster walls and ceilings and fresco paintings. The claim was assigned to Patrick Hurley. Hurley sent a letter discussing potential bars to coverage and requesting further information and documents from the Church. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES