District Court Awards Summary Judgment to Insurance Firm in Framing Case
August 4, 2011 — CDJ Staff
In the case of Continental Western Insurance Company v. Shay Construction Inc., Judge Walker Miller has granted a summary judgment against Shay Construction and their co-defendant, Milender White Construction Company.
Shay was the framing subcontractor for Milender White on what the court described as “a major construction project in Grand County, Colorado.” Two of Shay’s subcontractors, Wood Source Inc. and Chase Lumber Company furnished materials, labor, and equipment to Shay. They subsequently sued for nonpayment and sought to enforce mechanic’s liens, naming both Shay and Milender as defendants. Milender White alleged that Shay had “breached its obligation under its subcontracts with Milender White.”
Shay’s insurance provider, Continental Western, stated that its coverage did not include “the dispute between Shay, its subcontractors, particularly the cross claims asserted by Milender White.” Shay then sued Continental Western, alleging breach of contract and statutory bad faith.
The court, however, has found with Continental Western and has granted them a summary judgment. They found “no genuine issue as to any material fact.” The judge did not side with Continental Western on their interpretation of the phrase “those sums that the insured becomes legally obligated to pay as damages.” The court found that the Colorado courts have not limited this to tort actions only. However, as Milender’s cross claim included claims of faulty workmanship on the part of Shay, Judge Miller found for Continental.
Read the court’s decision…
Washington Court Limits Lien Rights of Construction Managers
August 17, 2011 — Douglas Reiser, Builders Counsel
A newly filed, yet unpublished, court opinion opines that a construction manager cannot file a construction lien in Washington state. So, how far reaching is this opinion?
In the case of Blue Diamond Group Inc. v. KB Seattle 1, Inc., et al, a New York construction manager filed a lien against the Westfield Southcenter Mall in Tukwila, Washington. The lien was filed after the owner of a coffee stand failed to pay Blue Diamond for consulting services used in the construction of a kiosk.
Blue Diamond served as the owner’s agent, assisting with managing subcontractors, vendors and other tasks. The manager’s tasks also included paying invoices, managing deliveries, setting schedules and other site managerial tasks. Blue Diamond was not registered as a contractor under Washington’s RCW 18.27.
Read the full story…
Read the court’s decision…
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com
Irene May Benefit Construction Industry
September 1, 2011 — CDJ Staff
Noting that while it wasn’t the $15 billion disaster some predicted, Hurricane Irene still caused quite a bit of damage on its path up the Eastern Seaboard. Martha White, reporting for MSNBC cites Kinetc Analysis Corp. with an estimate of $7 billion in damage. Carl Van Horn, a professor of public policy at Rutgers University expected an initial decline in construction jobs, due to projects delayed due to the storm’s arrival, but he said, “a few weeks later, employment picks up as people rebuild.”
Kinetic says that one unknown is how much of the damage is insured. They expect only $3 billion of damage will be covered by insurance. This would likely put a drag on consumer spending, as homeowners would have to dig into their own pockets to pay for repairs, according to Karl Smith, associate professor of economics and government at the University of North Carolina at Chapel Hill.
Read the full story…
Liability policy covers negligent construction: GA high court
October 31, 2010 — Original article by
Michael Bradford in Business Insurance
ATLANTA—Negligent construction that results in damage to surrounding property constitutes an occurrence under a commercial general liability policy, the Georgia Supreme Court has ruled.
In a 6-1 opinion Monday in
American Empire Surplus Lines Insurance Co. Inc. vs. Hathaway Development Co. Inc., the Georgia high court upheld a lower court ruling that the general contractor’s claim for damage caused by a subcontractor’s faulty plumbing work was covered.
The ruling on construction defects is the latest in number of such cases across the United States
Read Full Story...
Reprinted courtesy of Michael Bradford of Business Insurance.
Appropriation Bill Cuts Military Construction Spending
June 15, 2011 — CDJ Staff
The Hill reports that HR 2055, the Military Construction, Veterans Affairs (VA) and Related Agencies bill, has passed with only five votes in opposition. The bill cuts the budget for military construction spending by $2.6 billion due to anticipated base closures.
The bill includes $186 million for family housing construction by the Army, $100 million for family housing construction by the Navy and Marines, and $84 million for family construction by the Air Force, with an additional $50 million allocated for the DOD outside the military branches. By the act, these funds will remain available until September 30, 2016.
Read the full story…
Read HR 2055
Negligent Construction an Occurrence Says Ninth Circuit
June 30, 2011 — CDJ Staff
One June 27, the US Court of Appeals has rejected an appeal from Mid-Continent Casualty Company. Mid-Continent had appealed a summary judgment granted to Titan Construction Company.
Titan Construction had built condominiums for the Williamsburg Condominium Association, which later filed a construction defect lawsuit against Titan and other defendants. Titan settled with the developer, Kennydale, assigning its rights against Mid-Continent to Kennydale. Mid-Continent filed suit, claiming that “it had no obligation to indemnify or defend Titan, Kennydale, or various other defendants.” The district court found in favor of Mid-Continent, granting a summary judgment, concluding that Titan’s insurance covered “occurrences,” and none had taken place.
On appeal, the court found that the negligent construction of the condominiums constituted an “occurrence” The case was remanded and the district court this time found in favor of Titan, “concluding that Mid-Continent failed to raise a triable issue as to the applicability of the remaining policy exclusions.
The Ninth Circuit Court of Appeals has now affirmed that decision and Titan’s summary judgment stands.
Read the court’s decision…
Florida Construction Defect Case Settled for $3 Million
June 19, 2012 — CDJ Staff
The Runaway Beach Club Condominium Association of Kissimmee, Florida has settled its construction defect claims against the parties involved in the construction and development of the buildings. The association claimed that defective roofs and improperly installed windows had lead to leaks and associated damages. A trial date had been set, but parties involved were able to reach this settlement instead.
Read the full story…
Insurance Firm Under No Duty to Defend in Hawaii Construction Defect Case
September 13, 2012 — CDJ Staff
The US District Court for Hawaii has granted a motion for summary judgment in Evanston Insurance v. Nagano. The case is related to a construction defect claim, Hu v. Nagano, and the issue at hand is whether Evanston Insurance is obligated to defend the Naganos in the underlying case.
The Hus hired Eric Nagano and his firm PMX to construct a house. Mr. Nagano’s firm was insured by Evanston, however, he lost his contractor’s license in “approximately March 2006.” Mr. Nagano sought the Hus’ authorization to allow HC Builders to take over the contract. HC Builders is headed by Mr. Nagano’s wife, Hiroko, who has held a contractor’s license since “approximately September 2006.” Ms. Nagano and HC Builders were also insured by Evanston Insurance. The house, started by PMX was finished by HC Builders.
The Hus authorized construction to begin in July 2003, but “construction did not commence until approximately October 2004 and, even after commencement, there were numerous delays resulting in months of inactivity on the Project.” The Hus had expressed to Mr. Nagano and PMX “that the construction period could not exceed twelve months after July 1, 2003.” As a result of the delays, “the Hus’ community association fined them because of the prolonged construction and the Hus’ construction lender assessed extension fees and fines for exceeding the term of the loan.”
The Hus noted that the project did not have a licensed contractor from March through September 2006. In the end, the Hus “allege that Defendants did not fulfill the obligations under the Construction Contract,” and that “the Project was ‘grossly delayed’ and the construction was ‘riddled with defects.’” Despite an Owner’s Notice of Completion filed in December 2007, the residence “had no electricity, no hot water, ... no installed appliances” and “parts of the flooring were either missing or incomplete.” And then it leaked.
The Naganos tendered the defense to Evanston. The Naganos “allege the defense is limited because Evanston: allowed default to be entered against the Naganos (the default was later set aside); delayed retaining experts; and limited the ability of the Naganos’ retained counsel to perform necessary actions to advance the case.” Evanston argues that it “does not have a duty to defend or indemnify Defendants against the Hus’ claims,” as the Hus’ claims are not covered under the policy. Further, the PMX policies have an exclusion for breach of contract.
The court concluded that all of the claims made by the Hus were based in contract and therefore were outside of the terms of the Naganos insurance coverage, as the courts have "construed Hawaii law as not providing for insurance coverage for contract related claims." Therefore, Evanston does not have a duty to defend the Naganos.
Read the court’s decision…
Safer Schools Rendered Unsafe Due to Construction Defects
February 10, 2012 — CJD Staff
Built on a program for safer school buildings, schools in Neenan County, Colorado have been shown to have mild-to-moderate structural problems, rendering some of them unsafe. The Denver Post reports that a third-party review of schools built by the Neenan Company has shown structural issues in all fifteen school buildings.
One school, Meeker Elementary, has been closed as it could collapse under high winds or during an earthquake. Sargent Junior-Senior High School is in use, but there are plans to evacuate the buildings if winds exceed 25 mile per hour. Two schools have roofs that are unable to bear expected loads of snow during the winter.
The Neenan Company says that the school buildings are not up to their standards and is working with the school districts to repair the buildings. Repairs are expected to be complete by August.
Read the full story…
Insurer Able to Refuse Coverage for Failed Retaining Wall
October 28, 2011 — CDJ Staff
The Eleventh District of the US Court of Appeals has ruled in the case of Nix v. State Farm Fire & Casualty Company. In this case, the Nixes filed a claim after a portion of the retaining wall in their home collapsed and their basement flooded. State Farm denied the claim “on the ground that the policy excluded coverage for collapses caused by defects in construction and for damage caused by groundwater.”
The court reviewed the Nixes’ policy and found that State Farm’s statement did specifically exclude both of these items. In reviewing the lower court’s ruling, the appeals court noted that State Farm’s expert witness, Mark Voll, determined that the retaining wall “lacked reinforcing steel, as required by a local building code, and could not withstand the pressure created by groundwater that had accumulated during a heavy rainfall.” Additionally, a french drain had been covered with clay soil and so had failed to disperse the groundwater.
The Nixes argued that the flooding was due to a main line water pipe, but their opinions were those of Terry Nix and the contractor who made temporary repairs to the wall. “Those opinions were not admissible as lay testimony. Neither Nix nor the contractor witnessed the wall collapse or had personal knowledge about the construction of the Nixes’ home.”
The lower court granted a summary judgment to State Farm which has been upheld by the appeals court.
Read the court’s decision…
Late Filing Contractor Barred from Involving Subcontractors in Construction Defect Claim
March 1, 2012 — CDJ Staff
The Colorado Court of Appeals looked at that state’s Construction Defect Action Reform Act in determining if a general contractor could add subcontractors as third-party defendants to a construction defect lawsuit. Shaw Construction, LLC was the general contraction of the Roslyn Court condominium complex, and was sued by the homeowners’ association in a construction defect case. United Builder Services was the drywall subcontractor on the project. MB Roofing had installed roofs, gutters, and downspouts. The certificate of occupancy for the last building was issued on March 10, 2004. The project architect certified completion of all known remaining architectural items in June, 2004.
The HOA filed a claim against the developers of the property on January, 21, 2009. A week later, the HOA amended its complaint to add Shaw, the general contractor. Shaw did not file its answer and third-party complaint until March 29, 2010, sending its notice of claim under the CDARA on March 30.
The subcontractors claimed that the six-year statute of limitations had ended twenty days prior. Shaw claimed that the statute of limitations ran until six years after the architect’s certification, or that the HOA’s suit had tolled all claims.
The trial court granted summary judgment to the subcontractors, determining that “substantial completion occurs ‘when an improvement to real property achieves a degree of completion at which the owner can conveniently utilize the improvement of the purpose it was intended.’”
The appeals court noted that “Shaw correctly points out that the CDARA does not define ‘substantial completion.’” The court argued that Shaw’s interpretation went against the history and intent of the measure. “Historically, a construction professional who received a complaint responded by ‘cross-nam[ing] or add[ing] everybody and anybody who had a part to play in the construction chain.’” The court concluded that the intent of the act was to prevent unnamed subcontractors from being tolled.
The court further rejected Shaw’s reliance on the date of the architect’s certification as the time of “substantial completion,” instead agreeing with the trial court that “the architect’s letter on which Shaw relies certified total completion.”
The appeals court upheld the trial court’s determination that the statute of limitation began to run no later than March 10, 2004 and that Shaw’s complaint of March 29, 2010 was therefore barred. The summary judgment was upheld.
Read the court’s decision…
Insurance Company Must Show that Lead Came from Building Materials
August 17, 2011 — CDJ Staff
The Fourth Circuit Court of Appeals for Louisiana has reversed the summary judgment of a lower court in the case of Widder v. Louisiana Citizens Property Insurance Company. Judge Roland L. Belsome wrote the opinion for the panel of three judges. Ms. Widder discovered that her home and its content were contaminated by lead. She applied to her insurer, Louisiana Citizens Property Insurance, which denied her claim.
In response to Ms. Widder’s suit, LCPIC applied for a summary judgment on the grounds that there was no physical loss and that the policy did not cover defective material, latents defects, and pollution damage.
The appeals court found that the lead contamination of Widder’s home did meet the standards of a direct physical loss, citing a recent Chinese Drywall case. There, it was found, “when a home has been rendered unusable or uninhabitable, physical damage is not necessary.”
The lower court addressed only one of LCPIC’s exclusions, addressing only the exclusion on basis of “faulty, inadequate or defective material.” The appeals court noted that the evidence offered at trial does not show that the building materials were the source of the lead. This provided the appeals court with a matter of fact to remand to the lower court.
Read the court’s decision…
Repair of Part May Necessitate Replacement of Whole
February 10, 2012 — CDJ Staff
Judge Gleuda E. Edmonds, a magistrate judge in the United States District Court of Arizona issued a ruling in Guadiana v. State Farm on January 25, 2012. Judge Edmonds recommended a partial summary judgment in favor of the plaintiff.
Ms. Guandiana’s home had water damage due to pluming leaks in September 2004. She was informed that polybutylene pluming in her house could not be repaired in parts “it must be completely replaced.” She had had the plumbing replaced. State Farm denied her claim, arguing that “the tear-out provision did not cover the cost of accessing and replacing those pipes that were not leaking.”
In September 2007, State Farm filed a motion to dismiss. The court rejected this motion, stating that “If Guadiana can establish as a matter of fact that the system that caused the covered loss included all the pipes in her house and it was necessary to replace all the pipes to repair that system, State Farm is obligated to pay the tear-out costs necessary to replace all the pipes, even those not leaking.”
In March 2009, State Farm filed for summary judgment, which the court granted. State Farm argued that “the tear-out provision only applied to ‘repair’ and not ‘replace’ the system that caused the covered leak.” As for the rest of the piping, State Farm argued that “the policy does not cover defective materials.”
In December 2011, Ms. Guadiana filed for summary judgment, asking the court to determine that “the policy ‘covers tear-out costs necessary to adequately repair the plumbing system, even if an adequate repair requires replacing all or part of the system.”
In her ruling, Judge Edmonds noted that Ms. Guadiana’s claim is that “the water damage is a covered loss and she is entitled to tear-out costs necessary to repair the pluming system that caused that covered loss.” She rejected State Farm’s claim that it was not obligated to replace presumably defective pipes. Further, she rejected State Farm’s argument that they were only responsible for the leaking portion, noting “Guadiana intends to prove at trial that this is an unusual case where repair of her plumbing system requires replacement of all the PB plumbing.”
Judge Edmonds concluded by directing the District Court to interpret the tear out issue as “the tear-out provision in State Farm’s policy requires State Farm to pay all tear-out costs necessary to repair the plumbing system (that caused the covered loss) even if repair of the system requires accessing more than the leaking portion of the system.”
Read the court’s decision…
Can We Compel Insurers To Cover Construction Defect in General Liability Policies?
December 9, 2011 — Douglas Reiser, Builders Counsel
Recently, I read an article on Engineering News-Record that outlines a remarkable movement by as many as four states, to mandate coverage of construction defects in contractor general liability insurance policies. Say what? Is this a reality? What will become of affordable insurance?
Commercial General Liability insurance, or CGL, is your basic liability insurance. Every contractor doing business in the State of Washington, and most likely those abroad, has this insurance. Contractors buy this insurance to protect them from unforeseen liabilities arising from their negligence - and right now it’s reasonably affordable.
Why is it so affordable in such a risk-heavy industry? Because CGL policies significantly limit the scope of their coverage. Coverage is generally afforded for damages resulting from negligence (The roofer put a hammer through the drywall contractor’s wall) or which resulted from your defective construction (the roof leaked and flooded the rest of the house). But, that coverage does not include replacement of your faulty construction (the contents of the home might be protected by your leaky roof - the leaky roof itself is not).
The debate over coverage typically stems from the definition of “occurrence,” a term used to describe the event from which coverage arises, “resulting loss,” a term used to describe the type of loss covered.
Read the full story…
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com
Arizona Supreme Court Confirms Eight-Year Limit on Construction Defect Lawsuits
July 18, 2011 — CDJ Staff
Acting on the case of Albano v. Shea Homes Ltd. Partnership, the Arizona Supreme Court has ruled that Arizona’s eight-year statute of repose applies. The case was referred to the court by the Ninth Circuit Court of Appeals which had asked for a clarification of Arizona law. The case focused on three questions:
1. Does the filing of a motion for class certification in an Arizona court toll the statute of limitations for individuals, who are included within the class, to file individual causes of action involving the same defendants and the same subject matter? 2. If so, does this class-action tolling doctrine apply to statutes of repose, and more specifically, to the statute of repose for construction defects set forth in Arizona Revised Statutes ("A.R.S.") § 12-552? 3. If the doctrine applies to statutes of repose, and specifically § 12-552, may a court weigh the equities of the case in determining whether, and to what extent, an action is tolled?
The litigation at hand has a lengthy history, starting with a case referred to as “Hoffman” in 2003. The Albano plaintiffs were not able to join in Hoffman, and they filed their own lawsuit in 2006. An additional lawsuit was filed by the Albano plaintiffs in 2007. The courts decided that the Albano plaintiffs’ lawsuit was untimely.
The Arizona Supreme Court concluded that the statute of repose was the appropriate standard for this case. They noted that “the eight-year statute of repose period began to run on November 6, 1997, the date of the Town of Gilbert’s final inspection. Albano II was filed on November 5, 2007.”
The court found that the plaintiffs had waited too long for start their suit. As a result, they found it unnecessary to answer the first or third questions. Justice A. John Pelander of the Arizona Supreme Court wrote the opinion, dated June 30, 2011.
Read the court’s decision…
California Appeals Court Remands Fine in Late Completion Case
November 18, 2011 — CDJ Staff
The California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.
The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”
Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”
Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”
The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”
The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.
The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.
Read the court’s decision…
State Farm Too Quick To Deny Coverage, Court Rules
July 22, 2011 — CDJ Staff
On July 13, 2011, Judge Sarah S. Vance of the US District Court issued a rule in the case of Travelers Cas. & Surety Co. of Am. v. Univ. Facilities, Inc. (E.D. La., 2011). In this case, Stanley Smith Drywall was contracted by Capstone Building Corporation to “perform undisclosed work at the facility believed to involve the installation of drywall.” The project involved the design and construction of student residences for the Southeastern Louisiana University in Hammond, Louisiana. In May, 2009, University Facilities, Inc. (UFI) sued Capstone Development Corporation and Capstone On-Campus Management.
State Farm insured Stanley Smith Drywall and they sought a declaration that they have no duty: “(1) to insure Stanley Smith or CBC, or (2) to defend or indemnify any party against UFI's claims in the pending arbitration.” State Farm contends “(1) there is no "occurrence" to trigger coverage under the policy; (2) only breach of contract claims are asserted; (3) there is no property damage alleged; and (4) various coverage limitations and exclusions apply to prevent coverage.’
The court concluded that “whether State Farm has a duty to defend in the arbitration must be determined by considering the claims asserted in the arbitration.” However, the arbitration claims were not made part of the record. There, “, the Court cannot determine as a matter of law State Farm's duty to defend on the present record.” The same was true of State Farm’s duty to indemnify. “Stanley Smith and CBC assert that State Farm's motion for summary judgment was filed before any discovery was conducted in the arbitration proceeding or in this case. The Court finds that State Farm has failed to develop the record sufficiently to establish that there is no genuine issue of material fact as to its duty to indemnify Stanley Smith or CBC in the arbitration.’
The court denied State Farm’s motion for a summary judgment on its duty to defend and indemnify.
Read the court’s decision…
Brown Paint Doesn’t Cover Up Construction Defects
April 25, 2012 — CDJ Staff
In a decision that describes the case as illustrating “the perils that real estate brokers and their agents assume when acting as a dual listing agent to both the buyers and sellers of the same house,” the California Court of Appeals has issued a decision in William L. Lyon & Associates v. The Superior Court of Placer County. Lyon & Associates sought summary judgment to dismiss the claims of the Henleys who bought a home in a transaction where a Lyon agent represented both sides.
The prior owners of the home, the Costas, had used a Lyon agent in purchasing their home. When they later sought to sell it, that agent “became aware of some of the house’s defects and problems.” In response, the Costas sought the help of another agent, Connie Gidal, also of Lyons & Associates. Photos taken in the presence of Ms. Gidal show defects of the paint and stucco. The Costas also took the step of painting the house dark brown. During the sale process, “rain caused many of the painted-over defects to reappear.” The Costas “purchased more dark brown paint and covered up the newly visible damage prior to inspection by the Henleys.”
With the damage concealed, the Henleys bought the home in May 2006. The agreement with Lyons & Associates noted that “a dual agent is obligated to disclose known facts materially affecting the value or desirability of the property to both parties.” Escrow closed on May 9, 2006. The contract with the broker included a two-year limit on the time to bring legal action.
The Henleys moved in during June 2006, and “began to discover construction defects that had been concealed by the Costas.” In addition to the painted-over stucco problems, the Henleys found that the Costas had “installed quartzite stone overlays on the backyard steps in a manner that caused water intrusion on the house’s stucco walls.”
In May 2009, the Henleys sued the Costas, Ron McKim Construction, Lyons & Associates, and Ms. Gidal. Their complaint alleged that Lyons & Associates had committed breach of contact, negligence, fraud, breach of fiduciary duty, and negligent nondisclosure in connection with the construction defects. The Costas named Lyons in a cross complaint. Lyons moved for summary judgments on the grounds that the two-year statute of limitations had expired before the complaint and cross-complaint were filed. Both the Henleys and the Costas opposed this claim. The court denied the motion and Lyons appealed.
The appeals court upheld the denial, noting that the both California Supreme Court decision and later action by the legislature compels real estate brokers and salespersons “to conduct a reasonably competent and diligent visual inspection of the property offered for sale.” The court noted that under California law, brokers have responsibilities to both sellers and buyers. The section of law cited by Lyons applies to seller’s agents. The court rejected the contention by Lyons that they were “cooperating brokers.” The Henleys were “not constrained by the two-year statute of limitations.”
Lyons contended that even if California’s statute did not apply, there was a contractual limit of two years. The court also rejected this, agreeing with the Henleys that “the two-year limitation period must be extended by the discovery rule.”
The court noted that “Lyon & Associates may not reap the benefit of a shortened contractual limitation period when its own alleged malfeasance contributed to the delay in the discovery of the buyer’s injury.” The court found that the Henleys could proceed with their breach of contract claim, because, “when a breach of contract is committed in secret, such as the intentional nondisclosure of a real estate broker regarding a previously visible construction defect, the contractual limitations period is properly held subject to the discovery rule.” The court felt that the interpretation favored by the California Association of Realtors would “halve the applicable statute of limitations period.”
In addition to rejecting Lyon request for summary judgment on the claims made by the Henleys, the court also rejected the request of summary judgment on the claims made by the Costas, concluding that neither claim is time-barred. Costs were awarded to both the Henleys and Costas.
Read the court’s decision…
