Anaheim California Construction Expert Witness Directory

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Dispute Erupts Into Public Over Castro Theater Rehab Project Costs

September 08, 2026 — Richard Korman - Engineering News-Record
As it was about to start an arbitration of final payments on a complex theater renovation, the entertainment company that leases San Francisco's landmark Castro Theatre has filed a state court trademark violation lawsuit seeking to bar the contractor from publicizing as a success its work for the owner on that and other projects. Read the full story...
Reprinted courtesy of Richard Korman, Engineering News-Record
Mr. Korman may be contacted at kormanr@enr.com

Chambers USA Recognizes Hunton’s Insurance Coverage Practice in 2026 Guide

June 29, 2026 — Hunton Insurance Recovery Blog
Hunton is pleased to announce that its insurance coverage practice was recognized nationally for Insurance: Dispute Resolution – Policyholder in the recently released 2026 Chambers USA guide. The team also received state rankings in Florida (Insurance: Dispute Resolution), Georgia (Insurance), the District of Columbia (Insurance: Policyholder), and Massachusetts (Insurance). In addition to the insurance team’s group recognition across multiple states, the 2026 guide included individual rankings for Lorelie “Lorie” S. Masters (USA Nationwide and District of Columbia), Latosha M. Ellis (District of Columbia), Michael S. Levine (District of Columbia), Koorosh “KT” Talieh (District of Columbia), Walter J. Andrews (Florida), Andrea DeField (Florida), Cary D. Steklof (Florida), Lawrence J. Bracken II (Georgia), and Geoffrey B. Fehling (Massachusetts). Read the full story...
Reprinted courtesy of Hunton Andrews Kurth LLP

New York Orders Moratorium on Large Data Center Permits

July 27, 2026 — Levi W. Barrett - Peckar & Abramson, P.C.
Levi W. Barrett, Co-Managing Partner of Peckar & Abramson’s New Jersey office, Co-Chair of the firm’s Construction Contracts & Risk Management team, and Executive Committee Member, was recently quoted in “New York Orders Moratorium on Large Data Center Permits,” an article written by Engineering News-Record (ENR). The article examines New York Governor Kathy Hochul’s executive order temporarily halting state environmental permit reviews for certain large-scale data center projects while regulators develop a comprehensive framework to address the sector’s energy demands, water consumption, environmental impacts, and effects on local communities. It also explores the broader implications of the moratorium for developers, contractors, investors, and other stakeholders, as well as the ongoing debate between economic development, AI-driven infrastructure growth, and environmental and utility ratepayer concerns. Read the full story...
Reprinted courtesy of Levi W. Barrett, Peckar & Abramson, P.C.
Mr. Barrett may be contacted at lbarrett@pecklaw.com

Four HHMR Attorneys Recognized in the 2027 Editions of Best Lawyers®

September 21, 2026 — Higgins, Hopkins, McLain & Roswell, LLC - Colorado Construction Litigation Blog
Higgins, Hopkins, McLain & Roswell, LLC is proud to announce that Best Lawyers® has recognized four HHMR attorneys in the 2027 editions of The Best Lawyers in America® and Best Lawyers: Ones to Watch® in America for their work in construction law and construction litigation. David M. McLain, Lisa Bondy Dunn, and Steven L. Heisdorffer earned recognition in the 2027 edition of The Best Lawyers in America®. Ricky L. Nolen, Jr. earned recognition in the 2027 edition of Best Lawyers: Ones to Watch® in America. For a firm that has deliberately focused its practice on construction law and construction litigation for nearly 25 years, we take particular pride in seeing that focus reflected in the recognition of lawyers across different generations of HHMR. Read the full story...
Reprinted courtesy of Higgins, Hopkins, McLain & Roswell, LLC

Arizona Court Enters $323 Million Judgment Against ZOM Living Following Unanimous Jury Verdict

May 26, 2026 — Gray Development Group
PHOENIX, May 19, 2026 /PRNewswire/ -- A Maricopa County court has entered a $323 million compensatory damages judgment in favor of Gray Development Group against ZOM Holding Inc., doing business as ZOM Living, following a 12-day trial, a unanimous jury verdict and post-trial proceedings related to a proposed business transaction. The jury found ZOM liable on claims of breach of contract and breach of the implied covenant of good faith and fair dealing stemming from a proposed joint venture tied to a planned pipeline of luxury multifamily and commercial projects in Phoenix and Scottsdale. The lawsuit centered on a 13-project, $1.4 billion development pipeline originated and planned by Gray Development Group over more than a decade. In 2019, Gray invited Florida-based ZOM to participate in a joint venture involving the completion of five projects, which would have marked ZOM's entry into the Arizona market. According to court findings presented at trial, the companies entered into a mutual confidentiality and non-circumvention agreement before Gray shared extensive sensitive and proprietary information related to the projects, including planning, market analysis, costs, financial data, local business relationships and operational strategies developed by Gray over decades in Arizona. Evidence presented during trial showed that over a 10-month period while under contract, ZOM made hundreds of requests for confidential project and market information before circumventing Gray and pursuing the projects independently, ultimately displacing Gray from projects it spent years planning and developing. ZOM Living, headquartered in Orlando, develops multifamily and senior housing communities across the United States and operates regional offices in Boston, Dallas, Fort Lauderdale, Nashville, Phoenix, and Raleigh. ZOM is owned by Timeless Investments, the Amsterdam-based family office of Dutch businessman Hans van Veggel, which acquired the company in 1997. About Gray Development Group Gray Development Group was founded by architect Bruce Gray in 1991. The Phoenix-based company was the top-ranked multifamily developer in Arizona for more than a decade. The company designed and developed more than 15,000 apartment and condominium units throughout metropolitan Phoenix. Two Gray-designed developments — a Tempe midrise and a San Diego high-rise — received National Apartment Community of the Year awards.

Fight for Your Right: Effects of FAR Final Rule on Construction

October 12, 2026 — Michael Altman - Construction Executive
Since the Federal Acquisition Regulation final rule Use of Project Labor Agreements for Federal Construction Projects took effect, contractors seeking to compete for federal projects of $35 million or more must “negotiate or become a party to a project labor agreement with one or more labor organizations.” While this requirement significantly reduces competition for covered procurements, contractors may seek to restore competition on individual solicitations by filing a bid protest with the U.S. Court of Federal Claims. Bid protests through the COFC become possible once a federal agency posts a solicitation that includes contract provisions mandating a PLA. (In some cases, a presolicitation notice that a PLA mandate will be applied may be sufficient.) Reprinted courtesy of Michael Altman, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...
Mr. Altman may be contacted at altman@abc.org

Celebrating 29 Years – Thank You for Your Continued Trust!

April 20, 2026 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
For 29 years, Bremer Whyte Brown & O’Meara, LLP has grown alongside the clients and communities we proudly serve. What began as a single office in Orange County has evolved into a multi-state firm with 11 locations across five states. Today, we are proud to be supported by a dedicated team of more than 200 attorneys and over 400 employees who work every day to deliver exceptional service and results. This milestone is not just about where we started; it’s about the people who have helped shape who we are today. Our continued growth reflects the strength of our relationships, the trust of our clients and partners, and the commitment of our team. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES