ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Drilling Rig Topples at Citadel Miami Headquarters Site, Injuring Four

October 12, 2026 — Bryan Gottlieb - Engineering News-Record
An 85-ft drilling rig working at the site of Citadel's planned global headquarters in Miami toppled into Brickell Bay Drive Sept. 14, striking vehicles and a construction container, sending three workers and a motorist to hospitals. Read the full story...
Reprinted courtesy of Bryan Gottlieb, Engineering News-Record
Mr. Gottlieb may be contacted at gottliebb@enr.com

---

2026 Top Business Risks for Construction and Engineering Companies

May 26, 2026 — Darren Tasker - Construction Executive
The 2026 Allianz Risk Barometer revealed some surprising findings for construction and engineering businesses. Now in its fifteenth year, this annual business risk ranking by corporate insurer Allianz Commercial incorporates the views of 3,338 global risk management professionals on the main perils on their radar for the year. Survey respondents included construction and engineering risk experts who identified the threats keeping them up at night. Here is how they ranked the top industry risks for 2026: Natural Catastrophes Natural catastrophe risk retains the top spot, with 38% of construction and engineering respondents citing this risk as their leading concern for 2026. From the insurance perspective, economic and insured losses remained high, albeit lower than the 10-year average. The evolving nature of natural catastrophes continues to pose significant challenges to businesses and the (re)insurance industry. Insured losses from natural catastrophes are set to reach $107 billion for 2025, according to Swiss Re—the sixth year in a row they have exceeded $100 billion, while economic losses are well in excess of $200 billion. Reprinted courtesy of Darren Tasker, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Over 50 Lewis Brisbois Attorneys Recognized in 7th Edition of Best Lawyers: Ones to Watch in America

September 01, 2026 — Lewis Brisbois
56 Lewis Brisbois attorneys across 26 offices have been named to the 7th edition of “Best Lawyers: Ones to Watch in America.” Congratulations to the following attorneys on this recognition! You can see the full list of Lewis Brisbois attorneys named to Best Lawyers' 33rd edition of The Best Lawyers in America here. Akron, OH

• Partner Meleah M. Skillern - Commercial Litigation

Atlanta, GA

• Partner Catherine Crawley - Personal Injury Litigation – Defendants; and Transportation Law
• Associate Davis Lackey - Insurance Law; and Personal Injury Litigation – Defendants

Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Traub Lieberman Recognized in the 2026 Edition of Chambers USA

June 29, 2026 — Traub Lieberman
In the 2026 edition of Chambers USA, Traub Lieberman has been awarded rankings in the following categories: Illinois – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "The team are technically very strong, responsive, and on top of their cases." Florida – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "Traub Lieberman Straus & Shrewsberry distinguishes itself through a combination of deep subject-matter expertise, responsiveness, and practical risk-management orientation." Commenters went on to say: “The team has deep knowledge of Florida property insurance statutes, regulations and case law, enabling effective handling of disputes, appeals and third-party litigation." Read the full story...
Reprinted courtesy of Traub Lieberman

---

Motion for Summary Judgment Granted in Significant California Public Utilities Suit

May 12, 2026 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations to Partner Mike D’Andrea and Associates Ruth Rasiah and Kaylah Abdullah in the Los Angeles office for obtaining a complete dismissal of their clients in a significant claim involving California’s Public Utilities regulations. After lengthy litigation, BWB&O’s Motion for Summary Judgment was granted against Claimant, Spectrum (Charter Communications), which resulted in a complete dismissal of the action against BWB&O’s clients. At issue was whether California’s Public Utilities Code shifted the common law duty to maintain certain utility equipment in residential areas within Southern California. After significant briefing, the Superior Court found that BWB&O correctly argued that the Public Utilities Code required utility companies, like Spectrum, to fully maintain utility equipment, and that private residents are not responsible for utility maintenance (even if the physical equipment is located on private property). Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

---

Federal Bid Protest Standard of Review and Disparate Treatment with Ratings

August 16, 2026 — David Adelstein - Florida Construction Legal Updates
A recent decision out of the Federal Claims Court explains the post-award bid protest standard of review. In Massman Construction Co. v. U.S., 2026 WL 1971985 (Fed.Cl. 2026), a protestor brought a post-award bid protest after the Army Corps of Engineers awarded the contract to another contractor. The protestor argued that the Army Corps (government) acted irrational in its evaluation through disparate treatment. The Court of Federal Claims agreed and remanded for the Army Corps to “either justify this disparity or explain why [awardee’s] lower-priced, but technically inferior proposal provides the best value to the government.” Massman Construction, supra at *1. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Data Center Construction: Contractors Must Step Up

May 26, 2026 — Aarni Heiskanen - AEC Business
I attended the Datacenter Forum 2026 in Helsinki last week. Over 400 people packed the room. Walking out, I had one overriding thought: Is construction operating in a different century from the technology it is being asked to house? Is Our Industry on Par? Ciarán Forde, Senior Vice President at CTS Nordics, opened the forum with a statement that set the tone for everything that followed: data centers are no longer just a technical challenge; they are a national strategy. Before AI, Ciarán had worked in telecoms, where data centers were already complex. But now, he said flatly, everything has changed, and the industry must rethink everything. The numbers behind the claim are staggering. Current AI data center racks run at 40 to 100 kW. In three years, 800 kW per rack is on the roadmap. And the development cycle for a new chip is roughly one year, which means deployments begin aging out almost as soon as they are commissioned. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---