California Appeals Court Remands Fine in Late Completion Case
November 18, 2011 — CDJ Staff
The California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.
The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”
Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”
Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”
The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”
The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.
The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.
Read the court’s decision…
Arbitration Clause Found Ambiguous in Construction Defect Case
October 28, 2011 — CDJ Staff
The California Court of Appeals ruled on September 28 in the case of Burch v. Premier Homes. Ms. Burch bought a home after negotiating various addendums to the contract. The contract was a standard California Association of Realtors contract to which both the buyer and seller made additions. At issue in this case was paragraph 17 of the contract which included that “Buyer and Seller agree that any dispute or claim in Law or equity arising between them out of this Agreement or resulting transaction, which is not settled through mediation, shall be decided by neutral, binding arbitration.”
The seller/defendant’s Addendum 2 “included provisions relating to the arbitration of disputes that may arise.” Ms. Burch’s realtor, Lisa Morrin, told Burch that “she had never seen a proposed contractual provision that would require a home buyer to agree to arbitrate with a builder over construction defects.” Ms. Burch told Morrin that she did not want to buy the property if she would have to give up her rights under California law.
As part of Addendum 2, the buyer had to buy a warranty from the Home Buyers Warranty Corporation. The sale was held up for a while, as Ms. Burch waited for a copy of the warranty. When she received it, she took further exception to Addendum 2. Scott Warren of Premier Homes said he could not sell the property without Addendum 2. Ms. Burch told her realtor that despite the claims made by Mr. Warren that this was for her benefit, she felt it was more to the benefit of Premier Homes. Don Aberbrook of HBW agreed to the clause, contained in the final sentence of Addendum 2, being struck.
Subsequent to buying the home, Burch submitted a claim concerning construction defects. HBW denied the claim and Burch began an action against the defendants. Premier filed a motion to compel arbitration which Burch opposed.
The trial court ruled that the striking out of the arbitration clause at the end of Addendum 2 “created a conflict with respect to the parties’ intent as to the scope of arbitration.” The trial court found that “the parties’ intention was to preserve Burch’s right to make state law claims including her right to a jury trial for any non-warranty claims against the builder.”
The appeals court in their ruling looked at the standard of review and concluded that the purchase agreement was ambiguous and that extrinsic evidence was required to resolve that ambiguity. As the contract contained contradictory provisions as to whether or not arbitration was required, it was necessary for the trial court to examine these claims. The appeals court found that the evidence supported the conclusions of the trial court.
Finally, the appeals court found that “there was no valid agreement to arbitrate disputes.” The court noted that arbitration can only happen by mutual consent and “it is clear that Burch did not enter into an agreement to arbitrate any construction defect disputes she might have.”
Read the court’s decision…
Contractor Removed from Site for Lack of Insurance
October 28, 2011 — CDJ Staff
The MetroWest Daily News reports that a demolition firm was told to leave the construction site at Natick High School since their failure to have workers compensation insurance makes them unable to work on the project. The contractor, Atlantic Dismantling and Site Construction, Inc. may have been working illegally since September.
The equipment that Atlantic had rented for the job was repossessed in August. Brait Builders Corp, the general contractor for the site had rented equipment so Atlantic could continue their work.
Their lack of insurance was discovered when a worker had a minor job-related injury. The state had issued a stop-work order for the firm and they could not legally bid on public projects. The school system did not receive any notice of this, and the school’s facilities director said of the general contractor, “chances are Brait never heard of anything either.”
Read the full story...
No Third-Quarter Gain for Construction
November 18, 2011 — CDJ Staff
The Associated Builders and Contractors released their analysis of construction work under contract and found that there was no increase in construction backlog from the second quarter of 2011. There was still improvement, however, over 2010, as the third quarter backlog is 16.3 percent higher than that of a year ago.
The current backlog is 8.1 months, which according to Anirban Basu, the chief economist of the ABC, “is consistent with flat construction spending.” He noted that less than 8 months indicated a decline.
Read the full story…
Safer Schools Rendered Unsafe Due to Construction Defects
February 10, 2012 — CJD Staff
Built on a program for safer school buildings, schools in Neenan County, Colorado have been shown to have mild-to-moderate structural problems, rendering some of them unsafe. The Denver Post reports that a third-party review of schools built by the Neenan Company has shown structural issues in all fifteen school buildings.
One school, Meeker Elementary, has been closed as it could collapse under high winds or during an earthquake. Sargent Junior-Senior High School is in use, but there are plans to evacuate the buildings if winds exceed 25 mile per hour. Two schools have roofs that are unable to bear expected loads of snow during the winter.
The Neenan Company says that the school buildings are not up to their standards and is working with the school districts to repair the buildings. Repairs are expected to be complete by August.
Read the full story…
Tenth Circuit Finds Insurer Must Defend Unintentional Faulty Workmanship
December 9, 2011 — Tred R. Eyerly, Insurance Law Hawaii
Applying Colorado law, the Tenth Circuit found a duty to defend construction defect claims where the faulty workmanship was unintentional. Greystone Const. Inc. v. National Fire & Marine Ins. Co., 2011 U.S. App. LEXIS 22053 (10th Cir. Nov. 1, 2011). A prior post [here] discussed the Tenth Circuit’s certified question to the Colorado Supreme Court in this matter, a request that was rejected by the Colorado court.
In two underlying cases, Greystone was sued by the homeowner for damage caused to the foundation by soil expansion. In both cases, the actual construction was performed by subcontractors. Further, in neither case was the damage intended or anticipated. Nevertheless, National Union refused to defend, contending property damage resulting from faulty construction was not an occurrence.
Relying on a Colorado Court of Appeals case, General Security Indemn. Co. of Arizona v. Mountain States Mut. Cas. Co., 205 P.3d 529 (Colo. App. 2009), the district court granted summary judgment to National Union.
On appeal, the Tenth Circuit first considered whether Colorado legislation enacted to overturn General Security could be applied retroactively. The statute, section 13-20-808, provided courts "shall presume that the work of a construction professional that results in property damage, including damage to the work itself or other work, is an accident unless the property damage is intended and expected by the insured."
Read the full story…
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
CC&Rs Not the Place for Arbitration Agreement, Court Rules
May 24, 2011 — CDJ Staff
In January, the California Court of Appeals ruled that an arbitration clause inserted in a development’s CC&Rs by the developer could not be enforced. The case, Villa Vicenza Homeowners Association v. Noble Court Development, involved a case in which, according to the opinion, “following the first sale Nobel controlled the board of directors of the Association and because the initial condominium buyers noticed defects in common areas and common facilities and did not believe Nobel had provided a reserve fund sufficient to repair the defects, the condominium owners brought a derivative action on behalf of the Association against Nobel.”
The court concluded, “The use of CC&R's as a means of providing contractual rights to parties with no interest in or responsibility for a common interest development is also problematic from the standpoint of determining what if any consideration would support such third-party agreements. By their terms the CC&R's bind all successors, even those with whom a third party such as Nobel has never had any contractual relationship and to whom Nobel has not provided any consideration.” The court determined that “the trial court did not err in denying Nobel's motion to compel arbitration.”
Read the court’s decision
Construction Law Client Alert: Hirer Beware - When Exercising Control Over a Job Site’s Safety Conditions, You May be Held Directly Liable for an Independent Contractor’s Injury
April 6, 2011 — April 6, 2011 - By Mark VonderHaar and Yvette Davis in the Haight Brown & Bonesteel Blog
On February 24, 2011, the California Court of Appeal held in Jeffrey Tverberg, et al v. Fillner Construction, Inc. that the imposition of direct liability on a hirer turns on whether the hirer exercised retained control of worksite safety in such a manner that affirmatively contributed to the independent contractor’s injury. Twice, Tverberg, an independent contractor hired by a general contractor's subcontractor, asked the general contractor to make the job site safe by covering up open holes created by another unrelated subcontractor while Tverberg was working at the site. After Tverberg was injured at the site by falling in a hole, he sued both the general contractor and the subcontractor which had hired him.
The Court of Appeal reasoned that when the general contractor instructed another subcontractor to create a condition that was potentially dangerous (i.e., creating open and uncovered bollard holes), and simultaneously required Tverberg to perform unrelated work near the open holes, the general contractor s conduct may have constituted a negligent exercise of its retained control which affirmatively contributed to Tverberg’s injury. The Court also reasoned that the general contractor affirmatively assumed responsibility for the safety of the workers near the holes by only requiring stakes and safety ribbon, and negligently discharged that responsibility which resulted in injury.
Read the full story...
Reprinted courtesy of Mark VonderHaar and Yvette Davis of Haight Brown & Bonesteel. Mr. VonderHaar can be contacted at mvonderhaar@hbblaw.com and Ms. Davis at ydavis@hbblaw.com.
Lockton Expands Construction and Design Team
July 19, 2011 — CDJ Staff
Lockton Companies, LLC, the largest privately held independent insurance broker, has announced that it is expanding its construction and design team with the hiring of Karen Erger and Tom Miller.
Ms. Erger will provide professional liability practice management, loss prevention, contract and complex claims management consulting services to Lockton's architectural, engineering and construction clients in her role as Vice President, Director of Practice Management. Her background includes construction litigation at a leading construction law firm, professional liability claims defense and claims consulting for major professional liability underwriters.
Miller joins Lockton as a Senior Vice President within the Design and Construction Unit. His role will be dedicated to serving the needs of engineering, architecture and construction firms performing services around the globe. He has spent more than 15 years concentrating on professional liability for design professionals and contractors in multiple roles. He previously managed the professional liability underwriting of one of the largest construction insurers and has developed numerous manuscript insurance products as well as focused on strategic planning to enhance business unit opportunities.
Read the full story…
Landmark San Diego Hotel Settles Defects Suit for $6.4 Million
March 4, 2011 — April 4, 2011 Beverley BevenFlorez - Construction Defect Journal
After five years of legal battles, the condo owners of the El Cortez Hotel building in downtown San Diego settled for $6.4 million, as reported by The San Diego Union-Tribune on March 28, 2011. The Homeowners Association will net just over $3 million from the settlement.
The litigation may have had an adverse effect on the value of the condos within the El Cortez Hotel building. According to an article by Kelly Bennett of Voice of San Diego, “Many condos in the building originally sold for more than $600,000. Currently, the three units on the market are asking for just more than $200,000, the U-T said.”
Andrew Berman, the owners’ attorney, told The San Diego Union-Tribune that the five years of litigation included six lawsuits, 200 depositions, and multiple construction tests.
Read the full story... (San Diego Union Tribune)
Read the full story... (Voice of San Diego)
Geometrically Defined Drainage Cavities in EIFS as a Guard Against Defects
July 10, 2012 — CDJ Staff
The blog Stucco & Insulation Contractor writes up some details on a “relatively new modification to modern Exterior Insulation Finish Systems,” known as “geometrically defined insulation boards.” They note that the insulation has grooves cut in the back to provide a route for water to drain, instead of getting trapped. They note that when EIFS is installed by a skilled applicator, this is unnecessary. However, with less experienced (and cheaper) installers, problems are more likely.
By cutting these channels, the application of EIFS is rendered “idiot proof,” as they note. Their preference would be that EIFS installers take the time to do the job right, but call this “a step in the right direction.”
Read the full story…
Sometimes It’s Okay to Destroy Evidence
August 17, 2011 — CDJ Staff
The Minnesota Supreme Court has ruled in the case of Miller v. Lankow that Mr. Miller was within his rights to remediate his home, even though doing so destroyed the evidence of water intrusion.
Linda Lankow built a home in 1992. In 2001 or 2002, Lankow discovered a stucco problem at the garage which she attributed to moisture intrusion. She asked the original contractor to fix the wall. In 2003, Lankow attempted to sell her home, but the home inspection revealed fungal growth in the basement. Lankow made further repairs, including alterations to the landscaping.
In 2004, Lankow put her house on the market once again and entered into an agreement with David Miller. Miller declined to have an independent inspection, as the home had been repaired by professional contractors.
In 2005, Miller put the house on the market. A prospective buyer requested a moisture inspection. The inspection firm, Private Eye, Inc. found “significant moisture intrusion problems.”
Miller hired an attorney who sent letters to the contractors and to Lankow and her husband. Lankow’s husband, Jim Betz, an attorney, represented his wife and sent a letter to Miller’s attorney that Miller had declined an opportunity to inspect the home.
In 2007, Miller’s new attorney sent letters to all parties that Miller had decided to begin remediation work on the house. All stucco was removed. Miller then filed a lawsuit against the prior owners, the builders, and the realtors.
Two of the contractors and the prior owners moved for summary judgment on the grounds that Miller had spoliated evidence by removing the stucco. They requested that Miller’s expert reports be excluded. The district court found for the defendants and imposed sanctions on Miller.
The Minnesota Supreme court found that “a custodial party’s duty to preserve evidence is not boundless,” stating that “it may be particularly import to allow remediation in cases such as the one before us.” Their reasoning was that “remediation of the moisture intrusion problem in the home may be necessary, even essential, to address immediate health concerns.”
Given that Miller needed to remediate the problem in order to continue living there, and that he had given the other parties a “full and fair opportunity to inspect,” the court found that he was within his rights. The court reversed the judgment of the lower court and remanded it to them for review.
Read the court’s decision…
State Audit Questions College Construction Spending in LA
August 17, 2011 — CDJ Staff
A state audit of the Los Angeles Community College District found many problems with their construction spending. Their report, as described in the Los Angeles Times, found construction money spent for other purposes, such as promotional photography and public relation tours, $28.3 million spent on projects that were later cancelled, and oversight committees that provided no oversight.
Earlier this year, the LA Times ran a series of articles detailing problems with the Los Angles Community College District’s construction program. The LA Times reported that the State Controller’s audit reached many of the same conclusions.
The Community College District disputed the findings.
Read the full story…
Flooded Courtroom May be Due to Construction Defect
September 1, 2011 — CDJ Staff
The General Services Administration wouldn’t pin it on a construction defect, but a spokesperson said that a pipe that was misaligned during installation was the likely cause of a flood in the Thomas F. Eagleton US Courthouse on August 23. According to the St. Louis Dispatch, the burst pipe caused a 17-story waterfall in the courthouse, soaking ceilings and floors, and drenching the building’s contents.
The building was dedicated eleven years ago. During the nearly ten years before the building was complete, there were construction disputes and soil contamination issues.
Read the full story…
FHA Lists Bridges and Overpasses that May Have Defective Grout
September 13, 2012 — CDJ Staff
The Federal Highway Administration has released a list of bridges and overpasses that may be prone to corrosion problems due to grout that was in chlorides when it was supposed to be completely free of them. Currently, the FHA is working with state departments of transportation to determine if the defective grout was indeed used on additional bridges and overpasses. The initial FHA list of structures determined to have been built with the defective grout lists thirty-four sites, of which four are in Ohio, the largest number for any state.
California contains only one such site, the intersection of the 55 and 405 freeways, one of the few items on the list not designated as a bridge.
Read the full story…
OSHA Cites Construction Firm for Safety Violations
August 16, 2012 — CDJ Staff
S.J. Louis Construction of Texas Ltd. has been cited by OHSH for one serious and one repeat safety violation, according to a report in Insurance Journal. OSHA officials saw S.J. Louis employees working in an unshored trench along a highway service road. The company had cited for this violation previously. Without shoring of trenches deeper than five feet there is a risk of serious injury or death.
Read the full story…
Insurance for Defective Construction Now in Third Edition
November 7, 2012 — CDJ Staff
Available both in print and online, the International Risk Management Institute, Inc has brought out a third edition of Insurance for Defective Construction. The work is written by Patrick J. Wielinski of Cokinos, Bosien & Young, a Dallas-Fort Worth law firm. Mr. Wielinski practice focuses on insurance coverage. Insurance for Defective Construction is described as “a must read for anyone who buys, sell, or underwrites construction insurance or who becomes involved in construction claims.”
Read the full story…
Court finds subcontractor responsible for defending claim
May 18, 2011 — May 18, 2011 - CDJ Staff
In an unpublished decision, the California Fourth Appellate District Court has reversed the judgment of Judge Linda B. Quinn of the Superior Court of San Diego. In the case Inland California, Inc. v. G.A. Abell, Inland, a general contractor had subcontracted with Apache Construction and Precision Electric Company (G.A. Abell).
Apache alleged that extra demolition and drywall work was needed due to Precision’s electrical work. Inland tendered a defense of Apache’s claims. However, Precision did not provide any defense. Inland withheld payment from Precision.
At trial, Inland “conceded Precision earned the $98,000 in progress payments Inland withheld.” They were obligated to additionally pay Precision’s costs and attorney fees.
The Fourth Appellate District court has overturned this and remanded the case back to the lower court. The judges determined that Precision was obligated to defend itself against the claims raised by Apache and therefore vacated the judgment against Inland.
Read the court’s decision…
