When is a Construction Project truly “Complete”? That depends. (law note)
August 2, 2012 — Melissa Dewey Brumback, Construction Law North Carolina
Long-time readers of the blog may remember my earlier post on substantial completion. However, in looking over my blog stats to see what search terms lead people here, it looks like this is hot topic. The blog searches came in two general categories:
1. Those searching strictly for a definition of substantial completion. Some examples:
- What does “substantial completion” mean?
- when does a building achieve substantial completion
- contracts “substantial completion”
- substantial completion undefined
- when is a project substantially complete
Read the full story…
Reprinted courtesy of Melissa Dewey Brumback of Ragsdale Liggett PLLC. Ms. Brumback can be contacted at mbrumback@rl-law.com.
Official Tried to Influence Judge against Shortchanged Subcontractor
February 10, 2012 — CDJ Staff
A contractor testified in the trial of former Cuyahoga County Commissioner Jimmy Dimora. According to Fox 8 in Cleveland, Ohio, Sean Newman, the president of Letter Perfect testified that his company was a subcontractor on the reconstruction of the locker rooms at the Cleveland Browns Stadium. Newman said his company was paid only $400,000 of their $650,000 bid. When Letter Perfect sued the contractor, D.A.S. Construction, Dimora called the judge to influence her to rule in favor of D.A.S.
The judge in the earlier case, Bridgett McCafferty, has been found guilty of lying to the FBI during their investigation and is serving a 14-month prison sentence.
Read the full story…
Sometimes It’s Okay to Destroy Evidence
August 17, 2011 — CDJ Staff
The Minnesota Supreme Court has ruled in the case of Miller v. Lankow that Mr. Miller was within his rights to remediate his home, even though doing so destroyed the evidence of water intrusion.
Linda Lankow built a home in 1992. In 2001 or 2002, Lankow discovered a stucco problem at the garage which she attributed to moisture intrusion. She asked the original contractor to fix the wall. In 2003, Lankow attempted to sell her home, but the home inspection revealed fungal growth in the basement. Lankow made further repairs, including alterations to the landscaping.
In 2004, Lankow put her house on the market once again and entered into an agreement with David Miller. Miller declined to have an independent inspection, as the home had been repaired by professional contractors.
In 2005, Miller put the house on the market. A prospective buyer requested a moisture inspection. The inspection firm, Private Eye, Inc. found “significant moisture intrusion problems.”
Miller hired an attorney who sent letters to the contractors and to Lankow and her husband. Lankow’s husband, Jim Betz, an attorney, represented his wife and sent a letter to Miller’s attorney that Miller had declined an opportunity to inspect the home.
In 2007, Miller’s new attorney sent letters to all parties that Miller had decided to begin remediation work on the house. All stucco was removed. Miller then filed a lawsuit against the prior owners, the builders, and the realtors.
Two of the contractors and the prior owners moved for summary judgment on the grounds that Miller had spoliated evidence by removing the stucco. They requested that Miller’s expert reports be excluded. The district court found for the defendants and imposed sanctions on Miller.
The Minnesota Supreme court found that “a custodial party’s duty to preserve evidence is not boundless,” stating that “it may be particularly import to allow remediation in cases such as the one before us.” Their reasoning was that “remediation of the moisture intrusion problem in the home may be necessary, even essential, to address immediate health concerns.”
Given that Miller needed to remediate the problem in order to continue living there, and that he had given the other parties a “full and fair opportunity to inspect,” the court found that he was within his rights. The court reversed the judgment of the lower court and remanded it to them for review.
Read the court’s decision…
Construction Law: Unexpected, Fascinating, Bizarre
April 25, 2012 — CDJ Staff
Guy Randles offers an amusing set of odd construction law cases in the Daily Journal of Commerce, which he describes as “the unexpected, the fascinating and even the bizarre.” He noted that in one case “a whistleblower claimed he was terminated for reporting to the owner that the contractor’s painters had not applied the required coating thickness.” The whistleblower was the project manager and “was responsible for ensuring the proper coating thickness.”
A less amusing case was that of an architect who was arrested for manslaughter. Gerard Baker “told investigators that the considered the fireplaces to be merely decorative.” Randles notes that “the mansion’s fireplaces were built of wood framing and lined with combustible drywall.” Further, a “gas fireplace even vented into the house’s interior.” Building officials called the house “a death trap.” According to the LA police chief this may be the only case in which building defects lead to a manslaughter charge.
Read the full story…
Contract Not So Clear in South Carolina Construction Defect Case
November 7, 2012 — CDJ Staff
The South Carolina Court of Appeals has reversed a partial summary judgment issued by one of the lower courts in the case of The Retreat at Edisto Co-Owners Association v. The Retreat at Edisto. The underlying issues of the case deal with a construction defect complaint.
The lower court had concluded “Developer’s ‘First Amendment’ to the Master Deed required the Developer to satisfy the provision in the paragraph labeled ‘Master Deed Amendment or Phase II’ as a condition precedent to its election to proceed with the development of Phase II.”
The appeals court found that “the language of the First Amendment to the Master Deed is susceptible to more than one interpretation.” The court additionally concluded that the “Developer presented the requisite scintilla of evidence on the question of its intent in order to establish a genuine issue of material fact. As the material facts were in dispute, the appeals court reversed the summary judgment and remanded the case to the circuit court for further proceedings.
Read the court’s decision…
Supreme Court of Oregon Affirms Decision in Abraham v. T. Henry Construction, et al.
April 20, 2011 — April 20, 2011 Beverley BevenFlorez - Construction Defect Journal
After reviewing the decision in Abraham v. T. Henry Construction, et al., the Oregon Supreme Court affirmed that a tort claim for property damage arising from construction defects may exist even when the homeowner and the builder are in a contractual relationship.
When the case was initially filed, the plaintiffs alleged breach of contract and negligence. The defendants moved for summary judgment arguing that one, the claim was barred by the six-year statute of limitations and two, no special relationship (such as one between a doctor and patient) existed. The court agreed with the defendants. However, the Court of Appeals while affirming the trial court’s decision on breach of contract reversed the decision on negligence. The Court of Appeals stated that an administrative or statute rule could establish a standard of care independent from the contract.
The Oregon Supreme Court gave an example of cases where a tort claim could exist when a contract is present: “If an individual and a contractor enter into a contract to build a house, which provides that the contractor will install only copper pipe, but the contractor installs PVC pipe instead (assuming both kinds of pipe comply with the building code and the use of either would be consistent with the standard of care expected of contractors), that failure would be a breach of contract only. […] If the failure to install the copper pipe caused a reduction in the value of the house, the plaintiff would be able to recover that amount in an action for breach of contract. […] On the other hand, if the contractor installed the PVC pipe in a defective manner and those pipes therefore leaked, causing property damage to the house, the homeowner would have claims in both contract and tort. […] In those circumstances, the obligation to install copper instead of PVC pipe is purely contractual; the manner of installing the pipe, however, implicates both contract and tort because of the foreseeable risk of property damage that can result from improperly installed pipes.”
Read the court’s decision…
In Colorado, Repair Vendors Can Bring First-Party Bad Faith Actions For Amounts Owed From an Insurer
December 20, 2012 — Brady Iandiorio, Higgins, Hopkins, McLain & Roswell
With the aftermath of Sandy still being felt up and down the Eastern seaboard, the question of many victims turns to how they can rebuild their lives and homes. One of the first things many people do is call on their insurance carriers to help rebuild whatever damaged property they have. In a recent case here in Colorado, those rebuilding efforts got reaffirmed by a Court of Appeals case, Kyle W. Larson Enterprises, Inc., Roofing Experts, d/b/a The Roofing Experts v. Allstate Insurance Company, --- P.3d ----, 2012 WL 4459112 (Colo. App. September 27, 2012).
The facts of the case are pretty straightforward and could describe many repair vendors in numerous situations. Roofing Experts contracted with four homeowners insured by Allstate to repair their damaged roofs. The contracts provided that repair costs would be paid from insurance proceeds. The contracts also allowed Roofing Experts full authority to communicate with Allstate regarding all aspects of the insurance claims. Before work began, Roofing Experts met with adjusters from Allstate to discuss the four homes and the amount of each claim. After receiving approval for the claims, Roofing Experts began the repairs. During construction, Roofing Experts discovered additional repairs were necessary to maintain certain manufacturer’s warranties and to conform to applicable building codes.
Read the full story…
Reprinted courtesy of Brady Iandorio, Higgins, Hopkins, McLain & Roswell, LLC. Mr. Iandorio can be contacted at iandiorio@hhmrlaw.com
Contractor’s Home Not Covered for Construction Defects
September 13, 2012 — CDJ Staff
The US District Court in Seattle has rejected most of the claims made by a Des Moines man over insurance coverage for water damage to his home. Judge John C. Coughenour granted summary judgment to Liberty Northwest in Ayar v. Liberty Northwest Insurance Corporation.
Sayad Ayar was the general contractor for the construction of his house. As a homeowner held a $1.5 million insurance policy from Liberty Northwest (LNW) that excluded “faulty, inadequate, or defective construction.”
In 2008, less than three years after his house was constructed, Mr. Ayar filed a claim after water leaked through his living room ceiling. LNW hired an engineering firm to investigate the damage. The engineering firm, CASE Forensics, concluded that the water intrusion was due to “the failure to install an adequate and continuous waterproof membrane, flashing, and drainage system within the balcony at the time of construction.” Ayar’s expert attributed the leakage to “damage done to the weather deck waterproofing during a storm event with high winds,” which would be covered under the policy. CASE Forensics reviewed these conclusions and rejected them. LNW denied coverage.
Further problems lead to further investigations, and in each case, LNW attributed the problems to construction defects. During this process, LNW “authorized Ayar to cut into the ceiling’s drywall in order to assist in determining the source of the water intrusion.” Mr. Ayar moved his family to a rental home. He requested that LNW cover the rental and other other costs.
LNW’s adjuster concluded that no coverage was available, but recommended paying Mr. Ayar $19,648.68 to reinstall drywall and repair the hole in the ceiling. The insurance company paid $2,000 to cover the cost of cutting into the ceiling. The also claimed the amount of drywall he removed was “excessive” and would not cover his relocation as “his home had been livable and because the loss was not covered.”
Ayar made four claims to the court in support of the argument that LNW misrepresented “pertinent facts or insurance policy provisions.” The court rejected three of these, noting that as all water damage was excluded, LNW’s citation of other sources of water intrusion was not a misrepresentation. “LNW did not rely on this provision as the reason for denying coverage.” Nor was LNW’s reference to “fungi, wet or dry rot” a misrepresentation. As for their reference to construction defects, it “was clearly appropriate given that the construction defect exclusion was the principal basis or denying the claim.” However, the court found that regarding the removal of drywall, “a triable issue of the facts exists.”
Ayar also claimed that LNW did not conduct a reasonable investigation, but the court found no evidence to support this conclusion. “This is not a case where the insurer failed to investigate or did so only half-heartedly.” Although the thoroughness of the investigation could not questioned, the court concluded that its timing could. Ayar claimed that LNW engaged in unreasonable delays. LNW counters that the delays were due to “Ayar’s own obstructive behavior and failure to cooperate with LNW’s investigation.”
The court dismissed all of Ayar’s claims, with the exception of whether LNW should have informed him that they would not pay for drywall repair unless there was damage, and whether LNW’s investigation failed to conclude its investigation within a thirty-day time line.
Read the court’s decision…
Construction on the Rise in Denver
September 13, 2012 — CDJ Staff
In another sign of a recovery in the housing industry, the Denver Business Journal reports that the pace of new home construction has accelerated in the Denver area. According to the article, in the first seven months of 2012, forty-eight percent more permits were issued than in the first seven months of 2011. In July, 2012, there were sixty-six percent more permits than a year previously. For the Denver metropolitan area, July was the sixteenth consecutive month in which permits were up from a year previously.
Read the full story…
Negligent Misrepresentation in Sale of Building Altered without Permits
September 30, 2011 — CDJ Staff
The Supreme Court of New Hampshire has ruled in the case Wyle v. Lees. The Leeses owned a two-unit apartment building in North Conway, New Hampshire. They hired a contractor to add a third, larger apartment, including a two-car garage. The Leeses and their contractor submitted a building permit application. They were informed that site plan review was required. After receiving approval on the site plan, construction started. At no point did they obtain a building permit and the construction was never inspected. The Leeses subsequently added more space to the unit, reducing parking spaces below the minimum required. Again, they did not obtain a building permit.
In 2007, three years after all these changes were complete, the Leeses sold their building to Mr. Wyle. To the question “are you aware of any modifications or repairs made without the necessary permits?” they answered “no.” About six weeks after closing, Wyle “received a letter from the town code enforcement officer regarding the legality of the removal of a garage door from the new unit.” A subsequent inspection revealed “numerous building and life safety code violations.”
Mr. Wyle brought a claim against the Leeses for negligent misrepresentation. The defendants filed a motion “seeking to preclude economic loss damages.” At a two-day bench trial, Mr. Wyle won. The Leeses appealed.
The appeals court found that “the defendants negligently misrepresented that the premises were licensed for immediate occupancy and that the defendants had obtained all necessary permits,” and thus upheld the lower court’s finding of negligent misrepresentation. The appeals court also rejected the Leeses’ argument that damages must be apportioned on all parties, including “the plaintiff himself, the plaintiff’s building inspector, and the defendant’s contractor,” finding a lack of “adequate evidence.”
The Leeses further argued that they were unaware that modifications and repairs were accomplished without the required permits. The appeals court noted that “the trial court found that both the conditional approval and final approval for the site plan stated that a building permit and a certificate of occupancy were required prior to any use.” The court concluded that the Leeses “knew or should have known of the falsity of their representation.”
The appeals affirmed the findings of the trial court.
Read the court’s decision…
California Posts Nation’s Largest Gain in Construction Jobs
March 28, 2012 — CDJ Staff
California added about 8,900 construction jobs in January, 2012, as compared to December, 2011, leading the nation in the number of added construction jobs. Thirty-four other states also saw added construction jobs. A year prior, only twenty-eight states added construction jobs. The Associated General Contractors of America analyzed the monthly report from the Labor Department. Ken Simonson, the chief economist for the Associated General Contractors of America noted that “the gains this January partly reflect very mild weather this winter and exceptionally cold and snowy conditions a year before.”
Read the full story…
Plaintiffs In Construction Defect Cases to Recover For Emotional Damages?
March 16, 2011 — March 16, 2011 - Construction Defect Journal Staff
A recent post to the Markusson, Green, Jarvis Blog reports on an important appeals decision which promises to impact construction defect litigation in Colorado.
The post provides analysis on the recovery of inconvenience damages. The focus of the piece is centered on Hildebrand v. New Vista Homes II, LLC, 08CA2645, 2010 WL 4492356 (Colo. Ct. App. Nov. 10, 2010), wherein it was held that " the plain language of Construction Defect Action Reform Act permits recovery of damages for inconvenience, and that the trial court did not err by allowing inconvenience damages to go to the jury".
According to the MGJ Blog "The Hildebrand decision is important because it provides Construction Defect Plaintiffs with a foothold for collecting emotional damages. While several questions of law remain as to who or under exactly what circumstances a Plaintiff may recover these types of damages, the Hildebrand case has clearly set forth that emotional damages may be considered as part of actual damages pursuant to CDARA."
Read Full Story...
More Charges in Las Vegas HOA Scandal
September 13, 2012 — CDJ Staff
The indictments continue in the Las Vegas HOA scandal. A lawyer for the Justice Department told the judge in the case that “we expect several indictments before the end of the year.” According to the Las Vegas Review Journal, “a dozen or more” additional people will be charged in the conspiracy.
The judge in the case, Senior U.S. District Judge Lloyd George, told prosecutors that he wanted to address the issue of compensation for homeowners. Currently, defendants have agreed to pay $1.5 million to compensate homeowners associations and banks. Vistana homeowners have claimed that the conspirators got the bulk of a $19 million construction defect settlement.
Read the full story…
Harmon Tower Construction Defects Update: Who’s To Blame?
August 17, 2011 — CDJ Staff
Reporting on the site VegasInc.com, Liz Benton notes that “nobody wants to take the fall for what happened at Harmon.” Work on the Harmon hotel building in Las Vegas’s CityCenter stopped in 2008 after 26 of the planned 49 stories were completed. Lorence Slutzky, a construction law professor at John Marshall Law School and a partner with the Chicago firm Robbins Schwartz Nicholas Lifton & Taylor told Benton that while inspectors and others are complicit, “the real responsibility rests with Perini, which has an obligation to comply with the plan specifications.” Perini’s claim is that they were given faulty design drawings. MGM disputes this.
Perini has offered to repair the building defects, however MGM has released a statement that they have “zero confidence or trust that Perini can and will properly fix a building it has so badly constructed thus far.” One MGM spokesperson likened these requests from Perini to “the director of ‘Ishar’ demanding a sequel.” “Ishtar,’ cost Columbia Pictures $55 million dollars and earned only $4.2 million in its initial run. Perini claims that MGM halted work because of the economy.
Read the full story…
Tampa Condo Owners Allege Defects
October 23, 2012 — CDJ Staff
Owners in the Bel Mare towers have filed a lawsuit alleging that the building have construction defects that could lead to problems during periods with high winds. The Tampa Bay Business Journal reports that the condo association has sued the developer, the general contractor, the architects, the structural engineers, and subcontractors.
Read the full story…
California Appeals Court Remands Fine in Late Completion Case
November 18, 2011 — CDJ Staff
The California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.
The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”
Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”
Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”
The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”
The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.
The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.
Read the court’s decision…
Demand for Urban Living Leads to Austin Building Boom
August 16, 2012 — CDJ Staff
The New York Times reports that Austin is undergoing a building boom as a high-tech firms, including Facebook and Google, have moved into the downtown area. With them, comes a need for more apartment buildings and more retail space. Mike Kennedy, the president and chief executive of an Austin real estate firm, told the Times “the office space was here, the housing came, and retail is arriving last to the scene.” Currently, two large projects that will add about 500 apartment units is underway, including a 222-unit, 18-story building, and another that will contain 277 units. Apartment occupancy in Austin is at ninety-seven percent.
Developers also have hotels and more office space planned. The area has about 6,000 hotel rooms with an additional 2,000 planned, but events in Austin can bring in more people than the city’s 30,000 hotel rooms can accommodate. Office space is eighty-eight percent occupied, and a lack of office space could cause firms to look elsewhere.
Read the full story…
Courts Are Conflicted As To Whether "Good Faith" Settlement Determinations Can Be Reviewed Via Writ Petition Or Appeal
July 10, 2012 — Stephen A. Sunseri and Aarti Kewalramani, Gatzke Dillon & Ballance LLP
The Court of Appeal, Second District, Division Three, ruled in Oak Springs Villas Homeowners Association v. Advanced Truss Systems, Inc., et al., (June 14, 2012, B234568) __ Cal.App.4th __ [2012 WL 2149923], that a non-settling defendant cannot appeal a trial court's good faith settlement determination. Instead, a non-settling defendant may only file a petition for writ of mandate pursuant to Code of Civil Procedure section 877.6 to challenge a good faith determination. This decision comes on the heels of a 2011 ruling in Cahill v. San Diego Gas & Electric Co. (2011) 194 Cal.App.4th 939, which found that a writ petition is not the sole means of challenging a trial court's good faith settlement determination.
In Oak Springs Villas, supra, the condominium homeowners' association sued a developer, general contractor, and various subcontractors for alleged construction deficiencies and resultant property damage. The association eventually settled with the developer, but not with a truss manufacturer. The trial court approved the developer's motion for good faith settlement determination, and the truss manufacturer immediately appealed, instead of filing a writ petition. On appeal, the developer argued the good faith determination was not an appealable order. The truss manufacturer argued Cahill applied, as well as an older case, Justus v. Atchison (1977) 19 Cal.3d 564, which allowed for appeals when no remaining issues exist as to the appealing party.
The Court of Appeal ruled in the developer's favor and declined to follow Cahill, stating the truss manufacturer should have filed a writ petition, as expressly required under Section 877.6, subdivision (e). The Court also believed Justus was inapplicable because a non-settling party should not be allowed to have two review opportunities ?Äì one after an adverse good faith ruling, and then another after the ultimate conclusion of the case.
However, the greater effect is that Cahill and Oak Springs Villas simultaneously stand in conflict and appear to be valid law. One case allows for an appeal of a good faith settlement determination, while the other requires strict adherence to the statute. The Supreme Court is likely to review the issue. In the meantime, parties challenging good faith rulings are advised to consult the statutory requirements under Section 877.6, subdivision (e).
Printed courtesy of Stephen A. Sunseri and Aarti Kewalramani, Gatzke Dillon & Ballance LLP. Mr. Sunseri can be contacted at ssunseri@gdandb.com and Ms. Kewalramani can be contacted at akewalramani@gdandb.com.
